BidHits uses cookies to provide an individualized service and care for the privacy and protection of shared data.
By browsing this site, we understand that you agree to the terms of our Privacy Policy.
CCRC Kitchen Cooler Remediation - TWC is procuring removal and installation services for the large kitchen walk- in cooler portion of this project that requires replacement of existing single compressor with a 2- stage compressor set on the roof above the cooler.
Removal and installation services for a large kitchen walk- in cooler, including replacement of an existing single compressor with a 2- stage compressor set on the roof.
AI helper
Procurement for kitchen cooler remediation services, including removal of an existing single compressor and installation of a 2-stage compressor. Work will be performed in an occupied building. Responses are due July 17, 2026. Evaluation criteria include cost, past performance, project milestone schedule, and key personnel qualifications. A one-year contractor warranty is required.
Responses are due July 17, 2026, by 10:00 a. m. Central Time.
The awarded contractor will need to provide a one-year contractor warranty.
The award will be based on best value, considering cost (40%), past performance, qualifications, and experience (45%), project milestone schedule (15%), and the qualifications of key personnel.
Respondents must have been in business for a minimum of 3 years within the last 10 years, be currently licensed, financially solvent, and have submitted the response in accordance with submission instructions. A V PTS score of D or below will result in disqualification.
Liquidated damages are set at **** per day for this project. Failure to comply with disclosure requirements or produce records may also result in sanctions.
Failure to comply with communication restrictions, submit required signatures, provide incomplete responses, or meet minimum qualifications may result in disqualification.
Purchasing from People with Disabilities State Use Program Administrative Services - The Texas Workforce Commission ( TWC) is seeking to procure administration services for a Central Non- Profit Agency ( CNA) to organize and administer the State Use Program, as outlined in Chapter 122 of the Texas Human Resources Code and Title 40 of the Texas Administrative Code ( TAC), Chapter 806.
Administration services for a central nonprofit agency ( CNA) to organize and administer the state use program. Central nonprofit agency ( CNA) services for the state use program.
AI helper
Texas Workforce Commission (TWC) is seeking proposals for administration services for the State Use Program, managed by a Central Nonprofit Agency (CNA). The program aims to promote independence for individuals with disabilities through employment. The CNA will be responsible for recruiting and supporting Community Rehabilitation Programs (CRPs), managing program operations, delivering products and services, marketing, customer relations, and financial management. Key personnel, including an Account Manager and SPD Liaisons, are required. Responses are due August 12, 2026. Evaluation criteria include best value.
Responses are due August 12, 2026, by 10:00 a. m. Central Time.
The successful respondent must provide sufficient financial resources and/or the ability to maintain a line of credit to pay CRPs within thirty (30) business days.
The award will be based on best value determination.
Respondents must demonstrate experience in program management services to comparable clients of similar size and complexity to TWC, and provide staffing profiles and resumes for key personnel.
Unavailability of key personnel may result in the assessment of liquidated damages as set forth in section ****.
Failure to comply with communication restrictions, submit required forms, or provide complete information may result in disqualification.
**** BET Vending Multiple Locations - TWC seeks qualified vendors to provide beverage and snack vending machine services, including all labor, equipment, materials, installations, and maintenance services for the Texas Workforce Commission s Business Enterprises of Texas ( TWC- BET) program in Texas. It is TWC s intention to award one ( 1) or more Contracts as a result of this solicitation. Successful Respondents will ensure reliable vending operations that provide convenient access to food and beve
Beverage and snack vending machine services Multiple locations across Texas, including Abilene, Amarillo, Brownwood, Fort Stockton, Nacogdoches, San Antonio, Victoria, and Waco.
AI helper
Texas Workforce Commission (TWC) is seeking vendors for beverage and snack vending machine services across multiple locations in Texas. The contract will be awarded to one or more vendors. Key responsibilities include installation, servicing, maintenance, and ensuring reliable vending operations. Responses are due July 27, 2026. Evaluation criteria include commission percentage, technical approach, and past performance.
All machines must be delivered and installed no later than thirty 30 days after the beginning date of the contract.
Commissions are paid based on net sales, calculated from meter readings. Reports are due monthly.
The award will be based on best value, considering commission percentage (50%), technical approach (40%), and past performance, qualifications, and experience (10%).
Vendors must have been in business for at least five years or have principal owners with equivalent experience, be financially solvent, and have a satisfactory Vendor Performance Tracking System (VPTS) score.
Failure to comply with reporting requirements or other contract terms may result in remedies being assessed.
Questions and requests for clarification must be submitted by July 6, 2026.
Failure to meet minimum qualifications, submit required forms, adhere to communication restrictions, or provide timely responses can lead to disqualification.
2027 Apprenticeship Conference - The Texas Workforce Commission ( TWC) is seeking proposals toprovide Conference Services to include Meeting space, food/beverage services and sleeping rooms for the 2027 Apprenticeship Conference in one or more of thefollowing locations: Arlington, Texas, CorpusChristi, Texas, Conroe, Texas, Dallas, Texas, Denton, Texas, FortWorth, Texas, Galveston, Texas, Houston, Texas, SanAntonio, Texas, or TheWoodlands, Texas .
Conference services including meeting space, food/beverage services, and sleeping rooms for the 2027 Apprenticeship Conference. Meeting space, food/beverage services, sleeping rooms, registration area, exhibitor area, audio visual services.
AI helper
Texas Workforce Commission (TWC) is seeking proposals for conference services for the 2027 Apprenticeship Conference. Services include meeting space, food/beverage, and sleeping rooms in various Texas locations. Proposals are due July 20, 2026. The contract term is expected to end September 24, 2027, or October 1, 2027. Award will be based on best value. TWC encourages complimentary options such as free parking and discounted room rates.
Responses are due July 20, 2026, by 10:00 a. m. Central Time.
The award will be made to the respondent that offers the best value to the state, based on cost, past performance, qualifications, experience, and technical approach.
Respondents must have been in business for a minimum of three years, or principals must have relevant executive management experience. They must also be financially solvent and adequately capitalized.
Liquidated damages may be assessed for failure to perform contract requirements, with a ten percent remedy on monthly invoices for services until compliance is achieved, after a written demand and cure period.
Failure to comply with communication restrictions, submit required forms, or meet minimum qualifications may result in disqualification.
We selected the most helpful reviews from real users. Order may change periodically.
It encompasses all portals in one place.
G. Ferrea
All bids related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the bid documents.
R. M. Ferreira
The platform is very user-friendly.
N. Lobato
Excellent information. Just what I was looking for.
L. H. Borrelli
It helps me identify areas of opportunity and find bids related to my work area.
I. J. R. Beltran
The idea of ​​using a keyword and sending the information by email is very good.
U. Solutions
Simple, easy to use, and always up to date.
J. Z. Abi-zaid
The information helps me submit my bids on time for bids, and I also have readily available information on upcoming bids. So far, I am very satisfied with what I have received.
M. A. Z. Armenta
I get exactly what I asked for—quickly, daily, and simply. The search arrives pre-filtered, so there’s no time wasted digging through countless websites, and it’s always up to date!
P. C. O. Da Silva
Very good — I find exactly what I’m looking for. It’s a great experience.
G. Sigrist
Efficiency in search times.
R. Chavez
A complete, easy-to-use system. Support from calm, patient, and clear-teaching professionals.
BidHits is a government bid search engine that monitors official portals and brings relevant federal, state and local opportunities into one place. You can search on the site and receive scheduled email alerts.
Enter your email and activate the trial. For 14 days you can use the main features, including alerts and access to results. When it ends, if you do not subscribe at /subscription.php, the bid list becomes limited and you will not be charged automatically.
1) Add keywords that describe what you sell. 2) Start the trial. 3) Adjust regions, delivery times and email style after signup.
Whenever possible, yes. Some official portals require login or block direct links; in those cases we point you to the official process page so you can download the documents.
Yes. You can filter by region, procurement method, dates and value ranges. You can also save preferences for future alerts and searches.
Yes. In the dashboard you can see bids on a map and use it to plan follow-up by location.
It can happen. Smart Search uses your keywords to find related opportunities, not only exact matches. Add specific terms and remove off-topic results to improve future alerts.
Yes. You can query bids via API. Documentation at /api_integration.php. Ideal for CRM, BI and automations.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there is no auto-charge.
We monitor major official sources every day at the federal, state and local levels. New bid notices are added as soon as they are captured from the source portal.
Plans start at $ 43.00 per month, with options for different business needs and billing terms. Start with a free trial and evaluate the results before subscribing, with no automatic billing.
Add what you sell, get scheduled alerts, open documents or the official page, and use filters by region and method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the bid...
Loading summary...
Methodology
Unaided survey with 1070 active users, conducted through 07/15/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
