Fort Bliss City Bids, TX

The contractor shall begin performance within 5 calendar days and complete it within 180 calendar days after receiving award, notice to proceed.

The government shall pay the contractor the contract price as provided in this contract.

The government will award a contract resulting from this solicitation using the evaluation method lowest price technically acceptable.

The offeror must demonstrate a minimum of five years of experience performing commercial kitchen or restaurant type projects similar in size, scope, and complexity.

If the contractor fails to complete the work within the time specified in the contract, the contractor shall pay liquidated damages to the government in the amount of 1,**** foreach calendar day of delay.

The government has scheduled a one-day site visit at bldg **** at the intersection of mt. porchia street and cold war drive 09:00 a. m. mdt on 19 august 2026.

All offeror inquiries or questions shall be submitted in writing electronically at ***@***. *. * no later than 21 august 2026 by 4:00 p. m. mdt.

Offers evaluated as not technically acceptable will not be eligible for award, regardless of price.

The estimated magnitude of construction for this project is between 250,000. and 500,000.

The contract will be awarded to the responsible bidder whose bid, conforming to the invitation for bids, will be most advantageous to the government, considering only price. considering only price.

Prospective contractors must furnish Tab A (cover sheet with UEI, CAGE code, tax ID, authorized reps), Tab B (signed SF ****), Tab C (pricing), Tab D (bonding letter), Tab E (bid bond guarantee), Tab F (subcontractor list), Tab G (representations/certifications), and Tab H (digitally signed drawings). Failure to provide all of the above requirements shall render your bid nonresponsive.

If the contractor fails to complete the work within the time specified in the contract, the contractor shall pay liquidated damages to the government in the amount of 1,**** foreach calendar day of delay until the work is completed or accepted. the contractor shall pay liquidated damages to the government in the amount of 1,**** foreach calendar day of delay

A prebid conference will be conducted on 18 August 2026 at 09:00 am MST for the purposes of briefing on the bid requirements and answering questions regarding this solicitation. a prebid conference will be conducted on 18 august 2026 at 09:00 am mst

All questions and requests for information (RFI) must be received no later than 25 August 2026 at 4:00 pm MST. all questions and requests for information rfi must be received no later than 25august 2026 at 4: 00 pm mst.

Failure to provide all required tabs (A through H) will render the bid nonresponsive. Failure to provide all of the above requirements shall render your bid nonresponsive.

****

****

The contractor shall complete it within 180 calendar days after receiving award, notice to proceed. complete it within 180 calendar days after receiving award, notice to proceed.

Progress payments may be made monthly as the work proceeds, or at more frequent intervals as determined by the contracting officer. the government shall make progress payments monthly as the work proceeds, or at more frequent intervals as determined by the contracting officer

The government will award a contract resulting from this solicitation using the evaluation method lowest price technically acceptable. the government will award a contract resulting from this solicitation using the evaluation method lowest price technically acceptable.

The contractor must provide a superintendent at all times work is being performed on the project. the awardee of this contract will be required to provide a superintendent at all times work is being performed on the project

Work beyond the established pop without proper justification will result in liquidated damages being applied to the project in the amount of 1,**** us dollars per calendar day. Work beyond the established pop without proper justification will result in liquidated damages being applied to the project in the amount of 1,**** us dollars per calendar day.

A one-day site visit is scheduled at bldg **** at the mcgregor range nm complex installation 10:00 am mdt on 20 august 2026. the government has scheduled a one day site visit at bldg **** at the mcgregor range nm complex installation 10:00 am mdt on 20 august 2026.

Offers evaluated as not technically acceptable will not be eligible for award, regardless of price. offers evaluated as not technically acceptable will not be eligible for award, regardless of price.

The estimated magnitude of construction for this project is between 100,000. and 250,000. the estimated magnitude of construction for this project is between 100, 000. and 250, ****.

The contractor shall begin performance within 5 calendar days and complete it within 180 calendar days after receiving award, notice to proceed.

The government shall pay the contractor the contract price as provided in this contract.

The government will award a contract resulting from this solicitation using the evaluation method lowest price technically acceptable.

The offeror must demonstrate a minimum of five years of experience performing commercial kitchen or restaurant type projects similar in size, scope, and complexity.

If the contractor fails to complete the work within the time specified in the contract, the contractor shall pay liquidated damages to the government in the amount of 1,**** foreach calendar day of delay.

The government has scheduled a one day site visit at bldg **** at the intersection of mt. porchia street and cold war drive 09:00 a. m. mdt on 19 august 2026.

All offeror inquiries or questions shall be submitted in writing electronically at ***@***. *. * no later than 21 august 2026 by 4:00 p. m. mdt.

Offers evaluated as not technically acceptable will not be eligible for award, regardless of price.

The estimated magnitude of construction for this project is between 250,000. and 500,000.