Camp Maintenance Government Bids & RFPs

Offerors must have an active registration in SAM. gov. Offerors must have an active registration in sam. gov sam www. ***. *. *

Interested parties must submit to contracting officer, Anazette Andrews, at ***@***. *. * via email only no later than 10am on December 18, 2025. interested parties must submit to contracting officer, anazette andrews, at ***@***. *. * via email only no later than 10am on december 18, 2025.

The bid notice states work shall be completed within 90 days of notice to proceed, including removal, installation, testing, and final acceptance.

The bid notice states provide manufacturers warranty documentation 5 years on refrigeration system, 1 year on electrical and water systems.

The bid notice states The government is only interested in small business indian firms.

Offerors must be registered in the System for Award Management (SAM) in order to be eligible to receive an award from any government solicitation.

The magnitude of construction of this project is between $5,000,**** and $10,000,****.

The proposal submission deadline is January 14, 2026, at 10am. proposal submission deadline jan 14, 2026

The owner shall pay the contractor for the work described herein, subject to additions and deductions from approved and written change orders, in accordance with the amount stipulated in the signed agreement, at the completion of the work and acceptance by the owner. he owner shall pay the contractor for the work described herein, subject to additions and deductions from approved and written change orders, in accordance with the amount stipulated in the signed agreement, at the completion of the work and acceptance by the owner.

The proposal evaluation criteria and weighting factor for each shall be as follows: criteria points firm qualifications 35 project understanding and approach 35 project schedule 20 cost proposal 10 total 100 criteria points firm qualifications 35 project understanding and approach 35 project schedule 20 cost proposal 10 total 100

By signing below, the bidder certifies they are qualified and hold all licenses, permits and regulatory authority to perform the scope of work set forth in the bid description. by signing below, the bidder certifies they are qualified and hold all licenses, permits and regulatory authority to perform the scope of work set forth in the bid description.

In case of failure on the part of the contractor to complete the work as contractually specified, the firm shall be liable to the owner for all damages sustained by the firms failure to complete the work in an acceptable manner. in case of failure on the part of the contractor to complete the work as contractually specified, the firm shall be liable to the owner for all damages sustained by the firms failure to complete the work in an acceptable manner.

Attendance at the meeting is mandatory for all prime design firms intending to submit a response. attendance at the meeting is mandatory for all prime design firms intending to submit a response.

Questions and inquiries regarding this solicitation shall be submitted to the city no later than: 5: 00 pm on tuesday, january 6, 2026 questions and inquiries regarding this solicitation shall be submitted to the city no later than: 5: 00 pm on tuesday, january 6, 2026

The project was estimated at 8. 9m and the amount approved by cpst was 7m. he project was estimated at 8. 9m and the amount approved by cpst was 7m.