Lifeguard Government Bids & RFPs

The bid notice does not explicitly state a delivery deadline for the services. null

The bid notice does not specify the payment terms. null

The bid notice does not mention any warranty requirements. null

The bid notice does not specify the award criterion. null

The bid notice states that bidders attending the site inspection are required to complete the site inspection indemnity form or bring a copy of their certificate of insurance evidencing statutory worker’s compensation coverage. null

The bid notice does not mention any penalties. null

A non-mandatory prebid conference and site inspection will be held on March 31, 2026, at 10:00 AM. Bidders attending the site inspection are required to complete the site inspection indemnity form or bring a copy of their certificate of insurance evidencing statutory worker’s compensation coverage. null

The bid notice does not require sample submission. null

The bid notice does not specify a deadline for challenges or objections. null

The bid notice does not provide an estimated total value. null

The bid notice states that qualified firms or respondents are sought for the construction of the District 3 Aquatics Facility. The specific qualification criteria are not detailed in the provided text.

The contract is a 300 calendar day contract, with an additional 60 calendar days for alternates. The notice states, espondent understands and agrees that this is a 300 calendar day contract. 60 calendar days for alternates.

The bid notice states, city may determine which respondents proposal will provide the best value to city.

The bid notice states, each proposal received by city shall be analyzed to determine overall responsiveness and qualifications to the rfcsp.

The bid notice states, he contractor will be expected to begin construction in accordance with article 1 general provisions, section 1. 2. 4, notice to proceed and commencement of contract times in the general conditions city of san antonio construction contracts. in the event the selected respondent fails to achieve substantial completion and/or final completion of the project by the dates established for substantial completion and/or final completion, respondent hereby accepts and agrees it shall pay city the sum indicated on the table below for each and every calendar day of unexcused delay in achieving substantial completion and/or final completion beyond the scheduled completion/final completion dates.

The bid notice states, a nonmandatory site visit is scheduled on april 8, 2026, at 3:00 p. m. ct at the project site which is directly east of the mission theater marquee and adjacent to the harvey e. najim ymca, **** roosevelt ave, san antonio, tx ****.

The bid notice states, espondent must submit questions concerning this rfcsp through the civcast website at https:www. civcastusa. com/bids until april 17, 2026, at 4:00 p. m. ct, questions received after the stated deadline will not be answered.

The bid notice states, construction cost estimate: 3,440,****.

The camp shall commence at 11:00 am on 6 June 2026 through 11:00 am on 10 June 2026.

The notice encourages all small businesses to identify their capabilities in meeting the requirement.

The penalty for non compliance is the greater of a 500k or b the dollar amount expended, in excess of permitted levels.

Responses to this notice shall be e mailed to the contract specialist and contracting officer no later than 11 March 2026 at 11:00 a. m. est.