Window Glazing Government Bids & RFPs

Bids will be considered only if they are in the hands of DASNY by 2:00 pm local time on October 8, 2026.

DASNY has determined its interest is best met by use of a project labor agreement PLA on this project, seeking the best work at the lowest possible price.

The bidder or its principals shall have a minimum of five 5 years experience in similar work and shall provide a list of five 5 contracts of similar size, scope, and complexity.

Contacts made to other DASNY personnel regarding this procurement may disqualify the prospective bidder and affect future procurements with governmental entities in the state of New York.

**** to ****

A mandatory prebid meeting will be held on **** at 8:00 am the health and public services haps building located at 403 s 7th st, denton, md ****, room 111. bidders are required to attend.

Payments will be based on ninety percent 90 of total value of work completed and material in place as mutually agreed upon, less all previous payments. payments will be based on ninety percent 90 of total value of work completed and material in place as mutually agreed upon, less allprevious payments.

The contractor shall guarantee all materials, workmanship and the satisfactory operation of all equipment installed and/or finished, for a period of one 1 year from the date of the final acceptance of the entire work. the contractor shall guarantee all materials, workmanship and the satisfactory operation of all equipment installed andor finished, for a period of one 1 year from the date of the final acceptance of the entire work

Awards will be made to the lowest qualified, responsible bidder. awards will be made to the lowest qualified, responsible bidder.

Proposals must include manufacturer certifications and a statement confirming that all field personnel are direct, corporate trained employees. proposals must include the following distinct sections to be considered: o manufacturer certifications: documented proof that the bidding contractor is a certifiedauthorized installer of school guard glass andor safe haven defense systems.

If work is not completed by the specified date, liquidated damages of $1,**** for each calendar day will be deducted. if, in the districts judgment work is not completed by the specified completion date there shall be deducted from the amount due the contractor, as liquidated damages accruing to the district, the sum of 1, **** for each calendar day, per project, beyond the specified completion date until work is completed.

Each bidder shall carefully examine the drawings, read the specifications and all other contract documents, and visit the site of the work. each bidder shall carefully examine the drawings, read the specifications and all other contract documents, and visit the site of the work.

The district reserves the right to reject any bid from any contractor deemed unqualified by the district. the district reserves the right to reject any bid from any contractor deemed unqualified by the district.