Dept Of Defense- Dept Of The Air Force- U. S. Air Forces In Europe- Fa5641 764 Ess Pk - Agency Bids & RFPs

The full performance start date is o later than 28 January 2028, preceded by a 60 day transition period.

Site visits for both the türkiye and spain locations will be scheduled in close proximity to the rfp release date. Participation will be limited to a maximum of two representatives per company.

The delivery schedule is detailed in the delivery schedule, with different periods of performance for each line item, starting from December 1, 2026, to November 30, 2031. deliveries or performance line item delivery schedule quantity address and poc 2 months period of performance **** from 01 dec 2026 to 31 jan 2027 10 months period of performance **** from 01 feb 2027 to 30 nov 2027 500, 000 actual kilograms period of performance **** from 01 feb 2027 to 30 nov 2027 1 lot period of performance **** from 01 feb 2027 to 30 nov 2027 12 months option line item period of performance **** from 01 dec 2027 to 30 oct 2028 500, 000 actual kilograms option line item period of performance **** from 01 dec 2027 to 30 nov 2028 1 lot option line item period of performance **** from 01 dec 2027 to 30 nov 2028 12 months option line item period of performance **** from 01 dec 2028 to 30 nov 2029 500, 000 actual kilograms option line item period of performance **** from 01 dec 2028 to 30 nov 2029 1 lot option line item period of performance **** from 01 dec 2028 to 30 nov 2029 12 months option line item period of performance **** from 01 dec 2029 to 30 nov 2030 500, 000 actual kilograms option line item period of performance **** from 01 dec 2029 to 30 nov 2030 1 lot option line item period of performance **** from 01 dec 2029 to 30 nov 2030 12 months option line item period of performance **** from 01 dec 2030 to 30 nov 2031 500, 000 actual kilograms option line item period of performance **** from 01 dec 2030 to 30 nov 2031 1 lot option line item period of performance **** from 01 dec 2030 to 30 nov 2031

Payment will be made by code. 18a. payment will be made by code

The government will award a contract to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the government, price and other factors considered. a the government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the government, price and other factors considered. the following factors shall be used to evaluate offers: contracting officer shall insert the significant evaluation factors, such as i technical capability of the item offered to meet the government requirement ii price iii past performance see far **** and include them in the relative order of importance of the evaluation factors, such as in descending order of importance. technical and past performance, when combined, are contracting officer state, in accordance with far ****, the relative importance of all other evaluation factors, when combined, when compared to price.

If the contractor fails to deliver the supplies or perform the services within the time specified in this contract, the contractor shall, in place of actual damages, pay to the government liquidated damages of per calendar day of delay. a if the contractor fails to deliver the supplies or perform the services within the time specified in this contract, the contractor shall, in place of actual damages, pay to the government liquidated damages of per calendar day of delay contracting officer insert amount.

Potential offerors questions and comments regarding the draft rfq are due not later than 30 jan 26 **** central european time cet. potential offerors questions and comments regarding the draft rfq are due not later than 30 jan 26 **** central european time cet.

The government anticipates awarding a firm fixed price (FFP) purchase order for this effort.

Please submit your questions by **** Central European Time (CET) on Friday, 09 January 2026.