City Of Rio Grande City - Tx - Agency Bids & RFPs

The bid submission deadline is Thursday, May 21, 2026, at 11:00 AM. The bid notice states, The sealed proposals will be received until 11:00 am on Thursday, may 21, 2026.

The bid notice states that the contractor shall warrant all workmanship and materials for a period of one year from the date of final acceptance by the city. The contractor shall warrant all workmanship and materials for a period of one 1 year from the date of final acceptance by the city.

The bid notice indicates that proposals will be evaluated and ranked based on experience and qualifications, technical approach, past performance and references, proposed schedule, and cost proposal. Proposals will be evaluated and ranked according to the following criteria, using the rating sheet, labeled exhibit a: Criteria maximum points experience qualifications 25 technical approach 25 past performance references 15 proposed schedule 10 cost proposal 25 total 100.

The bid notice requires bidders to be qualified paving contractors and to submit information on their general experience, local experience, local office presence, and past performance. The city of rio grande city, is requesting sealed proposals from a qualified paving contractor to provide construction services for a street improvements project for overlay and street repairs.

The bid notice specifies liquidated damages for failure to complete the work within the specified time. Failure of the contractor to complete the work within the specified time shall result in liquidated damages in the amount of **** per calendar day.

The sealed proposals will be received until 11:00 am on Thursday, May 21, 2026.

The city reserves the right to reject any or all bids or to waive any informalities in the bidding process in accordance with the Texas Local Government Code Chapter 252.

Proposals are requested from a qualified paving contractor.

The bid notice states that the Statement of Qualifications will be due at 11:00 AM on Thursday, May 7, 2026.

The bid notice states that RFQs may be held by the City for a period not to exceed 60 days from the date the statement of qualifications was due for the purpose of reviewing and investigating the firms qualifications prior to the contract award.

The bid notice is a Request for Qualifications (RFQ) for professional engineering services to assist the Rio Grande City Public Library in the overall design of the broadband infrastructure and connectivity of the proposed 2026 library infrastructure facility improvement.

The bid notice does not require sample submission.

The deadline for submission of qualification statements is Thursday, May 7, 2026, at 11:00 AM. The bid notice states, The deadline for submission of qualification statements is Thursday, May 7, 2026 at 11:00 am.

The bid notice states, The proposal received will be evaluated and ranked according to the following criteria and using the rating sheet enclosed: Criteria maximum points Experience 60 Work Performance 25 Capacity to perform 15 Total 100. It also mentions, for the RFQ, the respondents qualifications will be evaluated, and the most qualified respondent will be selected, subject to negotiation of fair and reasonable compensation.

The bid notice requires firms to be registered to practice in the state of Texas and have an active registration with the System for Award Management (SAM. gov). It also asks for a transmittal letter, company profile with experience and qualifications, and a minimum of five references. The notice states, The city of rio grande city is seeking qualified to contract with an engineeringarchitectural surveying firm, registered to practice in the state of texas. and Firms must have an active registration with the system for award management www. ***. *. * and have been cleared not suspended or debarred.

The bid submission deadline is Monday, April 13, 2026, at 11:00 AM. The clock in the City Secretary's Office will be the official time clock.

The contractor shall warrant all workmanship and materials for a period of one (1) year from the date of final acceptance by the City.

Bids will be evaluated based on responsiveness to bid requirements, contractor qualifications and experience, compliance with applicable laws, and lowest responsible bid. Award will be made by the City Commission of Rio Grande City to the bidder who provides goods or services at the best value for the City.

Proposals will be evaluated and ranked based on experience and qualifications (25 points), technical approach (25 points), past performance and references (15 points), proposed schedule (10 points), and cost proposal (25 points).

Failure of the contractor to complete the work within the specified time shall result in liquidated damages in the amount of **** per calendar day.