Lease Contract Government Bids & RFPs

Offers must be submitted no later than December 28, 2026 by 4:30 PM Eastern. all offers must be submitted no later than december 28, 2026 by 4: 30 pm eastern to be considered.

Offerors must be registered and active in SAM. the offeror must be registered and active in the system for award management ( sam) at sam. gov

Offers submitted after the deadline or without ownership documentation may be rejected. offers submitted beyond this date is subject to rejection. any submissions received without documentation of ownership and or written authorization to represent owners are also subject to rejection.

Proposals must be submitted on or before the time and date provided on the first page of this RFP. The initial RFP solicitation will be open for a minimum of 60 days. Proposals must be submitted on or before the time and date provided on the first page of this request for proposals.

Rent will be negotiated with the selected offeror, with final rent at least equal to fair market value. Annual rent for first year is $10,****, subject to CPI adjustment. The fair market value annual rent for the first year of the lease is 10, ****.

Proposals are evaluated based on criteria including compatibility with preservation, financial capability, experience, environmental enhancement, and financial terms. the compatibility of the proposals intended use of the offered property with respect to preservation, protection, and visitor enjoyment of the park area.

Offerors must demonstrate capacity to plan, carry out, and finance their proposal. to be selected by the nps you must demonstrate that you have the capacity to plan, carry out, and finance your proposal.

Site tours are by appointment only. requests for site tours and questions about the rfp or the lease premises should be sent via email to: caco leasing@nps. gov.

Proposals over 20 pages will be deemed non-responsive. any proposals over these limits will be deemed non responsive and not evaluated further.

The fair market value annual rent for the first year of the lease is $10,****. The fair market value annual rent for the first year of the lease is 10, ****.

Anticipated completion date is October 08, 2027. the district has an anticipated completion date of october 08, 2027.

The district intends to award to the contractor whose proposal is determined to be the best value. award a leaseleaseback agreement for the project to the contractor whose proposal is determined to be the best value

Prequalification is mandatory. prequalification is mandatory for this project. respondents must achieve prequalified status prior to submitting their proposals.

Liquidated damages are specified for delays. liquidated damages established in the general construction provisions is for the same amounts as stipulated in article 4

A mandatory preproposal meeting and site walk will be held. a mandatory preproposal meeting and site walk will be held on november 19, 2026 at 9:00 a. m.

Proposers who do not attend the mandatory meeting will not be permitted to submit. proposers who do not attend the mandatory meeting and site walk will not be permitted to submit an rfqp