Strip Light Government Bids & RFPs

The bid notice does not specify a delivery deadline for the project. null

The bid notice does not specify payment terms. null

The bid notice does not specify warranty information. null

The bid notice does not specify the award criterion. null

The bid notice does not explicitly state qualification requirements for bidders. null

The bid notice does not specify penalties. null

A mandatory pre-bid conference will be required for all bidders on April 7, 2026, at 10 am. We will meet at the splash pad located at **** Church Avenue, Dade City, FL ****

The bid notice indicates that sample submission is not required. null

The bid notice does not specify a deadline for challenges. null

The bid notice states the project estimated budget is 0. 00. null

The bid submissions are to be received by April 14, 2026, at 4:00 PM.

The bid notice states that payment will be processed within forty-five (45) days from the date that the project has been completed, accepted by, and invoice received by Logan County, Oklahoma.

The bid notice specifies that all components of the apparatus are to be in good working condition when taken delivery with a minimum 90-day warranty on engine, transmission, drive axles, generator and pump internal parts.

The bidder must be able to provide performance, maintenance and payment bonds if the contract exceeds $100,000. The contractor shall procure and maintain, at the contractor's expense, a performance bond for the period of the contract project, including a one (1) year maintenance and work performance bond. The contractor is to supply Logan County with evidence of having and maintaining proper and complete insurance, specifically worker compensation in accordance with the laws of the State of Oklahoma, public liability and property damage insurance in the amount of $1,000,****.

Default in promised delivery date, or failure to meet specifications, authorizes the county to purchase supplies elsewhere and charge the full increase of cost and handling to defaulting contractor.

The contractor shall complete the entire work ready for use not later than 365 calendar days from notice to proceed. he contractor shall be required to a commence work under this contract within 5calendar days calendar days after the date the contractor receives the notice to proceed, b prosecute the work diligently, and c complete the entire work ready for use not later than 365 calendar days from notice to proceed.

The government will make progress payments to the contractor when requested as work progresses, but not more frequently than monthly, in amounts of 2,500 or more approved by the contracting officer, under the following conditions: he government will make progress payments to the contractor when requested as work progresses, but not more frequently than monthly, in amounts of 2, 500 or more approved by the contracting officer, under the following conditions:

The basis of evaluation will be the lowest responsive, responsible bid based on the total amount for the base bid items plus all the optional bid items. he basis of evaluation will be the lowest responsive, responsible bid based on the total amount for the base bid items plus all the optional bid items. line items **** thru ****.

This is a 100 small business setaside. 1. this is a 100 small business setaside.

If the contractor fails to complete the work within the time specified in the contract, the contractor shall pay liquidated damages to the government. if the contractor fails to complete the work within the time specified in the contract, the contractor shall pay liquidated damages to the government in the amount of first tier total costday 2, **** for each calendar day of delay until the work is completed or accepted. second tier total costday **** for each calendar day of delay until the work is completed or accepted.

Site visits may be arranged during normal duty hours by contacting: name: site visit will be announced through future amendment. b site visits may be arranged during normal duty hours by contacting: name: site visit will be announced through future amendment.

The anticipated magnitude of construction is between 5,000,00 and 10,000,000. he anticipated magnitude of construction is between 5, 000, 00 and 10, 000, 000.

The bid notice states he deadline for receipt of proposals is april 17, 2026 and must be received by the tribes, either by hand delivery, express delivery, electronic submission or regular mail no later than 3: 00 p. m. on that day pacific standard time.

Payment for work performed under the contract shall not exceed the agreed upon amount, unless otherwise agreed upon, in writing, by both parties. Payment shall be made to the contractor based on progress achieved. The contractor must submit each invoice in sufficient detail to document progress. Invoices will not be accepted on more frequent intervals than once a month.

The objective is to choose the contractor capable of providing a reliable and effective solution within a reasonable budget. An award will be made to a responsible indian bidder if within 10 of the lowest nonindian proposal price and defined experience.

The proposals will be evaluated on the basis of the following criteria and point ranges: responsiveness of the proposal, reasonableness of overall time estimates, qualifications and experience of responder, size and structure of firm and ability to maintain continuity of work, experience of responder in developing reports for tribes or other government entities, qualifications and experience of staff to be assigned, indian preference, and tero certification documented included.

The contractor site visit is not required. By submitting his/her proposal, the consultant acknowledges that he/she has satisfied him/herself as to the nature of the work.

All questions must be submitted no later than 3: 00 p. m. , april 3, 2026, pst.