The Texas Facilities Commission (TFC) is requesting proposals for the provision, delivery, and installation of furniture and fixtures for student housing, classroom expansion, and security entrance improvement at the Texas School for the Deaf (TSD) in Austin, Texas. The estimated budget is $473,**** must be submitted electronically via the OpenGov portal by September 10, 2026, at 3:00 pm CT. TFC anticipates multiple awards based on best value. Key requirements include demonstrating relevant experience in similar projects, providing a subcontracting plan, and adhering to TFC's terms and conditions.
The Kleberg building and Elizabeth street security entrance will be available on August 23, 2027 for delivery and installation.
Respondents should discuss warranties for the manufacturers furniture systems and fixtures to be installed in their proposed methodology.
TFC shall award to the respondents whose proposal is considered to provide the best value to the state of texas as defined by tgc, section ****.
Respondents must submit documentation including attachment f contractors qualifications form and demonstrate past experience performing this scope of work for the provision of modular and ancillary furniture and fixtures delivered and installed on a secure, special needs campus.
Contractors failure to complete the work within the contract time as required will cause damage to owner. these damages shall be liquidated by agreement of contractor and owner, in the amount of **** per day as set forth in the purchase order.
Samples shall be required for certain proposed substitute items as determined by the owner.
The deadline for submission of questions is August 31, 2026, 12:00 noon.
Proposals that fail to submit the bid bond, attachment b execution of proposal, attachment c subcontracting plan forms, attachment d compensation and fees package proposal forms, or attachment f contractors qualification form shall be disqualified.
****
