Waterproof Light Government Bids & RFPs

The bid notice states that prime contractors must be DCAMM certified in General Building Construction, and subcontractors must be certified in Electrical, HVAC, Plumbing, Masonry, Miscellaneous Metals, Waterproof Caulking, and Roofing Flashing.

The bid notice indicates a pre-bid conference is scheduled for April 1, 2026, at 11:00 AM at 2 Harris Street, Revere, MA ****, which implies a site visit is mandatory.

The bid notice does not mention any requirement for sample submission.

The contract is to be fully completed by October 31, 2026.

The bid notice does not explicitly detail payment terms beyond progress payments and final payment upon acceptance of the work.

The contractor shall warrant all material and equipment furnished and work performed for a period of one year from the date of written acceptance of the work.

The city shall award the contract to the lowest responsible and eligible bidder.

Bidders must be prequalified and certified by the Massachusetts Department of Transportation, Highway Division, and must include evidence of their ability to complete the work, the name of the superintendent and their experience, a DCAMM certificate, and a list of citations, judgments, contract terminations, and references.

Failure to complete the work by the specified dates will be subject to liquidated damages in the amount of $500 per day.

A non-mandatory pre-bid meeting is scheduled for 10:00 a. m. on March 26, 2026, at the project site located at 50 E. Merrimack St, Lowell, MA.

The bid notice does not explicitly mention a requirement for sample submission.

The bid notice does not specify a deadline for challenging the bid.

The contractor must complete the entire work ready for use not later than 365 calendar days after the date the contractor receives the notice to proceed. his requirement has a period of performance from **** with a completion date ofnot later than ****.

The government will award a contract to the responsible bidder whose bid, conforming to the solicitation, will be most advantageous to the government, considering only price and the price-related factors specified elsewhere in the solicitation. he government will evaluate bids in response to this solicitation without discussions and will award a contract to the responsible bidder whose bid, conforming to the solicitation, will be most advantageous to the government, considering only price and the pricerelated factors specified elsewhere in the solicitation.

Offerors or quoters are urged and expected to inspect the site where work will be performed. An organized site visit is scheduled for February 24, 2026 at 10:30 a. m. offerors or quoters are urged and expected to inspect the site where work will be performed. an organized site visit is scheduled for february 24, 2026 at 10: 30a. m.

Submit any questions to the contract specialist via email at ***@***. *. * not later than 9 march 2026 by 4: 00pm local time, warwick, ri. submit any questions to the contract specialist via email at ***@***. *. * not later than 9 march 2026 by 4: 00pm local time, warwick, ri.

The total value is estimated between $1,000,000 and $5,000,000. for purposes of disclosing the size of this project, offerors are advised that thetotal value is estimated between 1, 000, 000 and 5, 000, 000.

The contractor must complete the entire work ready for use not later than 365 calendar days after the date the contractor receives the notice to proceed. his requirement has a period of performance from **** with a completion date ofnot later than ****.

The government will award a contract to the responsible bidder whose bid, conforming to the solicitation, will be most advantageous to the government, considering only price and the price-related factors specified elsewhere in the solicitation. he government will evaluate bids in response to this solicitation without discussions and will award a contract to the responsible bidder whose bid, conforming to the solicitation, will be most advantageous to the government, considering only price and the pricerelated factors specified elsewhere in the solicitation.

Offerors or quoters are urged and expected to inspect the site where work will be performed. An organized site visit is scheduled for February 24, 2026 at 10:30 a. m. offerors or quoters are urged and expected to inspect the site where work will be performed. an organized site visit is scheduled for february 24, 2026 at 10: 30a. m.

Submit any questions to the contract specialist via email at ***@***. *. * not later than 9 march 2026 by 4: 00pm local time, warwick, ri. submit any questions to the contract specialist via email at ***@***. *. * not later than 9 march 2026 by 4: 00pm local time, warwick, ri.

The total value is estimated between $1,000,000 and $5,000,000. for purposes of disclosing the size of this project, offerors are advised that thetotal value is estimated between 1, 000, 000 and 5, 000, 000.