Marina Government Bids & RFPs

The bid due date is May 7th, 2026, at 2:00 PM. The bid notice states, bid due date: may 7th, 2026 @2: 00 pm.

The standard payment terms at the City of Antioch are net 30 days. The bid notice states, The standard terms at the city of antioch are net 30 days.

Contractor warrants all work done and goods provided under this agreement shall at the minimum: meet all conditions of the agreement, be free from all defects in design, material and workmanship, and be fit for the purposes intended. If any defects occur within 12 months following acceptance, contractor shall be solely responsible for the correction of those defects. The bid notice states, Contractor warrants all work done and goods provided under this agreement shall at the minimum: a meet all conditions of the agreement b shall be free from all defects in design, material and workmanship and c shall be fit for the purposes intended. If any defects occur within said 12 months following acceptance, contractor shall be solely responsible for the correction of those defects.

The bid will be awarded to the lowest responsive and responsible bidder offering the lowest price to the city, with best value based on all factors including cost, unit prices, total prices, contractor's ability, capacity, skill, character, integrity, reputation, judgment, experience, efficiency, quality of performance on previous contracts, and ability to provide future maintenance, repair, parts, and services. The bid notice states, The bid will be awarded to the lowest responsive and responsible bidder offering the lowest price to the city and will be announced by way of publishing to the citys website bid documents. best value is based on all factors, including: cost unit prices and total prices contractors ability, capacity andrfp contract specifications page 2 of 13 keep these pages for your records skill ability to perform within the time required character, integrity, reputation, judgment, experience and efficiency of contractor quality of contractors performance on previous purchases or contracts, if applicable and the ability of the contractor to provide future maintenance, repair, parts and services, if applicable.

The contractor shall, at a minimum, possess a valid and active general building contractor B license issued by the state of California. The bid notice states, The contractor shall, at a minimum, possess a valid and active general building contractor b license issued by the state of california.

If delivery does not occur on schedule, the contractor shall pay the city the sum of five hundred dollars (****) per day for each calendar day of delay. The bid notice states, it is agreed that the contractor shall pay to the city the sum of five hundred **** dollars per day for each calendar day delay in finishing the contract as specified in section 3. 2. 8 period of performance and liquidated damages of the attached example agreement.

There will be a mandatory pre-bid site meeting on April 15th at 10:00 AM at the Antioch Marina located at 5 Marina Plz, Antioch, CA **** to this meeting is required for any vendor wishing to bid on this project. The bid notice states, There will be a mandatory prebid site meeting on april 15th at 10: 00am at the antioch marina located at 5 marina plz, antioch, ca **** to this meeting is required for any vendor wishing to bid on this project.

Protestors are urged to seek resolution of their complaints initially with the using department. Any actual or prospective bidder, or contractor that has a grievance in connection with any city solicitation or award of contract may protest in writing pursuant to the provisions in Antioch Municipal Code section 34. 03. The bid notice states, Any actual or prospective bidder, or contractor that has a grievance in connection with any city solicitation or award of contract may protest in writing pursuant to the provisions in antioch municipal code section **** are urged to seek resolution of their complaints initially with the using department.