Inquiry Government Bids & RFPs

All work must be completed within 120 working days. The document states: all work under this agreement shall be completed and submitted for final acceptance within 120 working days.

Payment is due 30 days after delivery and acceptance. The document states: prices bid must be based upon payment in thirty (30) days after delivery and acceptance.

A two-year maintenance bond is required. The document states: the maintenance and repair of any and all defects in workmanship or materials. . . for a period of two (2) years from the date of the final acceptance.

Award is made to the lowest responsible and responsive bidder. The document states: award will be made to the lowest responsible and responsive bidder according to the criteria designated in the invitation for bid.

Louisiana contractor license is required for bids over $50,000. The document states: on any public works bid submitted in the amount of $50,000 or more, the contractor shall certify that he or she is licensed under Louisiana Revised Statute 37:2150.

Liquidated damages apply for late completion. The document states: for each calendar day or workday. . . that any work shall remain uncompleted after the contract time. . . the sum specified below will be deducted.

Questions must be submitted at least 7 working days before bid opening. The document states: any inquiry received at least seven (7) or more working days prior to the date fixed for the opening of bids will be given consideration.

Failure to provide required forms results in non-responsiveness. The document states: if any of the required information is not provided, then your bid will not be considered or accepted.

The designer's estimate is $820,****. The document states: designers estimate: 820,****.

Bids must be submitted by October 29, 2026, at 10:00 AM EST. The notice states: until 10:00 a. m. (e. s. t) on thursday, october 29, 2026.

Bidders must comply with state antibidrigging regulations and submit an executed noncollusion affidavit. The notice states: bidders must comply with all state antibidrigging regulations pertaining to work associated with this project will be required to submit an executed noncollusion affidavit with the bid.

Questions are due by October 22, 2026, at 4:00 PM EDT. The notice states: questions due date: oct 22nd 2026, 4:00 pm edt.

Bids submitted by any other means than online via PennBid will not be accepted. The notice states: bids submitted by any other means will not be accepted.

Qualification statements must be received by 11:00 a. m. prevailing time on November 6, 2026. qualification statements must be received by the agency no later than 11: 00 a. m. prevailing time on november 6, 2026

Evaluation considers which are the most advantageous, price and other factors considered including quality, experience, knowledge, price proposal, staffing, and other factors.

Respondents must demonstrate professional, financial, and administrative capabilities. the agency will consider qualification statements only from respondents that. . . have demonstrated the capability and willingness to provide high quality services

Incomplete or non-responsive qualification statements may be rejected. the agency reserves the right. . . to reject any respondent that submits incomplete responses to this rfq, or a qualification statement that is not responsive to the requirements

Work must be completed within 60 calendar days. The contract states: all work under this agreement shall be completed and submitted for final acceptance within 60 consecutive calendar days from the time so fixed for the contractor to begin.

Payments are made monthly based on estimates. The document states: payments will be made to the successful bidder as follows: on or before the 30th of each month an invoice listing in detail the amount of each item of construction complete in place and the amount of work performed will be furnished to the project manager.

A two-year maintenance bond is required. The document states: the maintenance and repair of any and all defects in workmanship or materials which may develop or occur in the above referenced project, free of any and all cost to the city of shreveport, for a period of two 2 years from the date of the final acceptance of the project.

Award will be made to the lowest responsible and responsive bidder. The document states: award will be made to the lowest responsible and responsive bidder according to the criteria designated in the invitation for bid.

Contractors must be licensed for public works bids of $50,000 or more. The document states: on any public works bid submitted in the amount of 50, 000 or more, the contractor shall certify that he or she is licensed under louisiana revised statute 37: ****, et seq. and show is or her license number on the outside of the bid envelope and on the bid schedule.

Liquidated damages apply for late completion. The document states: for each calendar day or workday, as specified, that any work shall remain uncompleted after the contract time specified for the completion of the work required by the contract, the sum specified below will be deducted from any money due the contractor not as a penalty but as liquidated damages.

Site visit is required before bidding. The document states: bidders are required to visit the job site prior to submitting a bid, for the purpose of becoming familiar with site conditions, specific job requirements, and to take or verify measurements as appropriate.

Questions must be submitted at least 7 working days before bid opening. The document states: any inquiry received at least seven 7 or more working days prior to the date fixed for the opening of bids will be given consideration.

Failure to submit required forms will result in non-responsiveness. The document states: if you do not provide all of the required cos bid forms or the information required on the bid forms, then your bid must be declared as nonresponsive.

The designer's estimate is $300,****. The document states: designers estimate: 300, ****