Pile Rehabilitation Government Bids & RFPs

Payment will be made by Visa or Mastercard. payment on this contract will be made by visa or mastercard

Contractor must correct defective work within one year after completion. the contractor agrees to correct any defective or faulty work or material, which may appear within one 1 year after completion of the work and receipt of final payment

Requires a current Florida general contractor license and at least 10 years of bridge construction experience. possession of a current general contractors license issued by the state of florida is required and the contractor shall have at least ten 10 years previous bridge construction and maintenance experience

A prebid conference and site visit will be held on November 6, 2026. a prebid conference will be held on november 6, 2026, 10: 00 am local time and while attendance is not mandatory, tours at other times might not be available

Protests must be delivered within 5 days after notice of intent to award is posted. may protest to the procurement services department director, by delivering a letter of protest within five 5 days after a notice of intent to award is posted

Bids may be rejected if informal, unbalanced, or contain inadequate prices. no bid will be canvassed, considered or accepted which, in the opinion of the city is informal or unbalanced, or contains inadequate or unreasonable prices for any items

Project completion date is September 3, 2027. The project shall be completed within forty-five (45) days of starting date. project completion date: september 3, 2027

Contractor must provide a current letter from MDOT granting prequalification FA, bridges and special structures. a current letter from mdot granting prequalification fa, bridges and special structures

Liquidated damages will be assessed for failure to complete by the specified date. liquidated damages will be assessed for failure to complete this project by the specified date

Bids must be submitted prior to 2:00 pm ET, Tuesday, November 3, 2026. The submit button will deactivate at exactly 2:00 pm ET.

The authority reserves the right to award the bidder whose price is the lowest, based on total bid amount.

Bidders must provide a complete set of most recent audited financial statements and list a minimum of four projects similar in nature with a contract value no less than $500,000 over the past ten years.

Failure to execute the agreement will result in forfeiture of the bid guaranty as liquidated damages.

A mandatory prebid conference and site visit will be held on Thursday, October 15, 2026, at 10:00 am ET, via Zoom. Attendance is mandatory.

Respondents shall file any protest regarding this ITB in writing, in accordance with Jaxport's protest procedures promulgated on SOP ****.

Failure to acknowledge all addenda may result in rejection of the bid. Bids received via email, fax or hand delivery will be declared nonconforming.

The work must be completed within 6 months or 180 calendar days from start of the project. The work will be completed and ready for final inspection within 6 months or 180 calendar days from start of the project.

Partial payments are made monthly with 5% retained until final completion. there shall be retained five percent 5 on the amount of each estimate until final completion and acceptance of all work covered by the contract.

The contractor must remedy defects appearing within 18 months from final acceptance. the contractor shall remedy any defects in the work and pay for any damage to other work resulting therefrom that shall appear within a period of eighteen 18 months from the date of final acceptance of the work.

Bidders must provide at least three professional references for similar services in the past five years. provide at least three 3 or more professional, business references with which you have contracted to provide similar services in the past five 5 years.

Liquidated damages of $500 per day for delay. the contractor shall pay to the city fixed, agreed, and liquidated damages in the amount of either fivehundreddollars 500 per day for each calendar day of delay until the work is satisfactorily completed.

A mandatory prebid meeting will be held onsite. a mandatory prebid meeting will be held on **** at 10: 00 am est onsite at 700 passagrille way, st. pete beach, fl ****.

Questions must be submitted in writing by 10/28/2026 at 10:00 AM EST. all questions pertaining to the terms and conditions or scope of work of this request for bid rfb must be sent in writing email is acceptable to the city procurement manager and shall be received no later than 10: 00 est on ****.

Failure to submit all requested documents may deem the bid ineligible. failure to submit all documents requested at the time of bid may deem the contractors bid ineligible for award.

The work of construction must be completed within 556 working days after the date in the notice to proceed. The work of construction must be completed within 556 working days after the date in the notice to proceed.

Unless all bids are rejected, award will be given to the low, responsive, responsible bidder. award will be given to the low, responsive, responsible bidder.

Each prime contractor intending to bid this job shall attend a mandatory jobsite walkthrough. Each prime contractor intending to bid this job shall attend a mandatory jobsite walkthrough

A mandatory jobsite walkthrough will be held at 10:00 am on 10/15/2026 at **** The Old Road, Valencia, CA **** jobsite walkthrough to be held at 10:00 am on **** at **** the old road, valencia, ca ****

The last day for submitting questions to the district will be close of business 5 working days prior to the bid opening date. The last day for submitting questions to the district will be close of business 5 working days prior to the bid opening date.

Only those bidders who have obtained and properly downloaded the bid documents from this website will appear on the plan holder list and may submit an electronic bid. Only those bidders who have obtained and properly downloaded the bid documents from this website will appear on the plan holder list and may submit an electronic bid.