Environmental Remediation Government Bids & RFPs

Proposals are due by 9/9/2026 at 2:00 PM. The RFP states: proposal due **** 2: 00pm.

The town will select the proposal that represents the best overall value based on the evaluation criteria identified in this rfp.

Minimum 5 years of experience and 3 completed PFAS projects required. The RFP states: Minimum of five (5) years of continuous experience providing environmental investigation, remediation, and/or hazardous waste management services.

Questions regarding this RFP must be submitted by 10/5/2026 at 5:00 PM. The RFP states: questions due **** 5: 00pm.

Late proposals may not be considered. The RFP states: late proposals may not be considered.

This solicitation is for small business set aside program vendors only. this solicitation is for small business set aside program vendors only.

A nonmandatory walkthru is scheduled for October 6th at 9:30am. a nonmandatory walkthru is scheduled for october 6th at 9:30am.

Failure to complete and upload vendor disclosure or IPG active registered vendor disclosure will result in disqualification. failure to complete and upload will result in disqualification

This solicitation is for small business set aside program vendors only. this solicitation is for small business set aside program vendors only.

A nonmandatory walkthru is scheduled for October 7th at 10:00 am. a nonmandatory walkthru is scheduled for october 7th at 10:00 am.

Failure to complete and upload vendor disclosure will result in disqualification. failure to complete and upload will result in disqualification

Work must be completed by March 31, 2027. The contractor agrees to commence work within 30 calendar days after receipt of notice to proceed, and complete all work by March 31, 2027. complete all work by march 31, 2027

Payment will be made within 30 days of acceptance of the work by the contracting officer. No partial payments will be considered. payment will be made within 30 days of acceptance of the work by the contracting officer

The award may be made to the responsible bidder that best meets the needs and interests of the service district, taking into consideration quality and performance. best meets the needs and interests of the service district, taking into consideration quality and performance

Bidders must demonstrate successful work experience in similar stream restoration projects. References will be consulted and past performance evaluated. successful work experience in similar stream restoration projects weighs heavily in determining whether a bidder has the technical competence

Liquidated damages of **** per calendar day for each day the work exceeds the completion period. pay the sum of **** per calendar day as liquidated damages to the service district for each calendar day that the work exceeds the period

Bidders should visit the site to ascertain conditions and extent of work. Failure to do so will not relieve contractor from responsibility. bidders should visit the site and take such other steps as may be reasonably necessary to ascertain the conditions of the site

Incomplete or nonconforming bids may result in rejection. Electronically submitted email or fax bids will not be accepted. incomplete or nonconforming bids may result in rejection of the bid