Stone Repair Government Bids & RFPs

The closing date for this solicitation is February 26, 2024.

Only online bids will be accepted for this RFB. Emailed and hard copies delivered by any method will not be accepted.

The closing date for bids is January 10, 2024, with the closing time at 22:08:922200000.

Emailed and hard copies delivered by any method will not be accepted. only online bids will be accepted for this rfb.

The project will have an estimated period of performance of 330 calendar days after receiving notice to proceed.

Respondents must include company contractor name, address, point of contact, phone number and e mail address, company's interest in bidding, company's capability to perform a contract of this magnitude and complexity including comparable work performed within the past 10 years (at least 3 examples), identification of small business classification, and bonding capacity.

Do not submit a response to this sources sought if you do not intend to bid on this project. Do not submit proprietary and or business confidential data.

The estimated magnitude of construction is between 1,000,000 and 5,000,000.

The estimated price range for this project is over $20,000,****.

Bids must be submitted on or before Thursday, July 30, 2026, at 4:00 PM prevailing time. sealed bids will be received for the following project: 517 swede street historical fa�adeimprovements in the office of the norristown department of planning municipal development, 235east airy street, floor 2, norristown, pa ****, on or before thursday, july 30, 2026 @4: 00 pmprevailing time.

The owner shall make payments on account to the contractor as provided in the general conditions. Retainage of 10% will be withheld from each payment request. he owner shall make payments on account to the contract as provided herein under the general conditions.

The contractor agrees to warranty all materials and workmanship for one year after the final completion date. upon final completion and acceptance of the project, the contractor agrees to warranty all materials and workmanship required by the contract documents for one year after the final completion date.

Consideration will be given to bids received from qualified bidders that perform quality work for the lowest responsible price. consideration will be given to bids received from qualified bidders that perform quality work for the lowest responsible price.

Bidders must be properly licensed under the laws governing their respective trades and be able to obtain insurance required for the work. bidders must be properly licensed under the laws governing their respective trades and be able to obtaininsurance required for the work.

If the contractor neglects to complete the work by the final completion date, they shall credit the owner **** for each calendar day of default. if contractor neglects, refuses or fails to complete the work by the final completion date specified in **** ownercontractor agreement paragraph 2a, unless otherwise amended by owner, contractor shall credit the owner the sum of five hundred dollars and nocents **** for each and every calendar day that the contractor is in default in completing the work within the time specified.

A mandatory pre-bid conference will be held at the project site on Thursday, July 16, 2026, at 10:00 AM. a mandatory prebid conference will be held at the project site on thursday, july 16, 2026 at 10:00am

All questions must be submitted via email prior to Thursday, July 23, 2026, at 5:00 PM ET. all questions must be submitted prior tothursday, july 23, 2026 at 5: 00pm et.

Bids may be rejected if the bidder fails to furnish required information, misstates or conceals material facts, does not conform to requirements, is conditional, incomplete, or deemed unqualified. he owner reserves the right to reject any or all bids when such rejection is in his interest and to reject any bid for one or more of the following: a. the bidder fails to furnish any of the information required pursuant to the instructions to bidders.