Timber Harvesting Government Bids & RFPs

Payment is due within 3 business days after the grantee receives reimbursement from the funder. payment of each invoice shall be due and payable within three (3) business days after the grantee receives reimbursement from the funder.

Contractor faces $250/day fine for late start and $50 per trash instance. the twc project manager will assess contractor a 250 fine per day and may fine the contractor 50 per instance of trash/litter discovered on site.

The government will award a firm fixed price contract to the responsible quoter whose quote is most advantageous to the government as determined by the solicitation evaluation criteria.

All responsible sources may submit a quotation. NAICS code **** with small business size standard of 500 employees.

Amendment 001 changes the site visit date from Thursday, October 22, 2026 to Thursday, October 29, 2026.

Timber must be cut and removed by 1 November 2028 for item 1, and 31 December 2027 for items 2 and 3. The contract states: cut and remove from the sale area all timber designated for harvest under this sale agreement on or before 1 november 2028 for item 1, and 31 december 2027 for items 2 and 3.

For contracts above $5,000, 20% of bid price is required within 10 days of acceptance. The document states: 5, 000 or 20 percent of the bid price, whichever is greater, is required within ten 10 days after notice of acceptance of the bid.

Bidders must complete a small business status certificate. The document states: all bidders should complete the certificate as to small business status set forth below. this certificate must be completed and made a part of every invitation to bid on the sale of governmentowned timber with an estimated value of 2, 000 or more.

Liquidated damages apply for various violations. The document states: failure to complete harvesting operations on or before expiration date. one 1 percent per month of the value of the estimated timber remaining unharvested, or a minimum charge of 100, whichever is greater.

Inspection is invited and encouraged. The document states: inspection of lump sum contract areas is invited and encouraged between 8: 00 a. m. and 4: 00 p. m. , monday through friday, excluding holidays. arrange inspection with mrs. stephanie price, project forester, telephone number ****.

Appeals must be filed within 90 days. The document states: the decision of the real estate contracting officer shall be final and conclusive unless, within ninety 90 days from the date of receipt of such copy, the contractor mails or otherwise furnishes a written appeal to the corps of engineers board of contract appeals.

Bids without proper deposit will not be considered. The document states: no bid will be considered unless it is accompanied by a deposit in the amount of 24, **** for item 1, 12, **** for item 2, and 10, **** for item 3.

The purchaser agrees to cut and remove all designated timber on or before 31 December 2027. the purchaser agrees to cut and remove from the sale area all timber designated for harvest under this sale agreement on or before 31 december 2027.

Advance payments required: for contracts over $1,000, $1,000 or 20% of estimated purchase price, whichever is greater. for all other contracts, 1, 000 or 20 percent of the estimated purchase price, whichever is greater, is required.

Bidders must complete a small business status certificate. all bidders should complete the certificate as to small business status set forth below.

Liquidated damages include **** per stump for failure to cut stumps properly. failure to cut stumps in accordance with specifications. ten dollars **** per stump.

Inspection of salvage areas is invited between 8:00 a. m. and 4:00 p. m. , Monday through Friday. inspection of current known salvage areas is invited between 8: 00 a. m. and 4: 00 p. m. , monday through friday, excluding holidays.

Disputes must be appealed within 90 days from receipt of the decision. within ninety 90 days from the date of receipt of such copy, the contractor mails or otherwise furnishes a written appeal to the armed services board of contract appeals.

Bids without the required $1,000 deposit will not be considered. no bid will be considered unless it is accompanied by a deposit in the amount of 1, **** for item 1.

All submissions are due Friday, 16 October 2026. all submissions are due friday, 16 october 2026.

Evaluation factor is price only. amendment **** attached with update to evaluation factors to price only.

Site visit scheduled for Thursday, 24 September 2026, **** CDT. site visit scheduled for thursday, 24 september 2026.

Questions deadline is Thursday, 8 October 2026. questions deadline: thursday, 8 october 2026.