Container Ship Government Bids & RFPs

Delivery must be completed within 30 days of receiving the purchase order. delivery must be completed within 30 days of receiving the purchase order.

The county terms of payment are 2/10 net 30. county terms of payment are 2 10 net 30.

The contract allows for an extension of up to twelve 12 months from the date of expiration provided such extension is mutually agreeable. the county reserves the right to extend the contract under the same terms and conditions for up to twelve 12 months

The vendor must be primarily engaged in the commercial sale, leasing, or modification of shipping containers. the vendor must be primarily engaged in the commercial sale, leasing, or modification of shipping containers.

Liquidated damages of **** per calendar day will be assessed for late delivery. liquidated damages in the amount of **** per calendar day for each day the delivery is delayed

Protests or disputes must be in writing during the bid opening period. vendors protesting or disputing bid specificationstime of bid opening, must do so in writing during the bid opening period

Failure to meet qualifications, such as not owning the quoted container or failing to meet delivery timelines, may result in rejection. failure to meet these stipulations will result in the immediate rejection of the bid or cancellation of the purchase order

The first article must be delivered within 60 calendar days from the date of this contract to the government at contact buyer on page one for testing location within 60 calendar days from the date of this contract to the government at contact buyer on page one for testing location

A pre award survey and post award conference may be required for all new manufacturers. a pre award survey and post award conference may be required for all new manufacturers.

If the contractor fails to deliver any first article on time, or the contracting officer disapproves any first article, the contractor shall be deemed to have failed to make delivery within the meaning of the default clause of this contract. if the contractor fails to deliver any first article on time, or the contracting officer disapproves any first article, the contractor shall be deemed to have failed to make delivery within the meaning of the default clause of this contract

All unless otherwise provided for in the contract, samples shall be returned to the contractor and may be considered as production items under the contract provided the sample s can be refurbished to ready for issue condition and provided the sample s have inspection approval from the cognizant dcmc qar. all unless otherwise provided for in the contract, samples shall be returned to the contractor and may be considered as production items under the contract provided the sample s can be refurbished to ready for issue condition and provided the sample s have inspection approval from the cognizant dcmc qar.

Delivery is required by **** days ado