The solicitation is for a DBDBB, IDIQ MACC for general construction services to serve NAVFAC Midatlantics Marine Corps Installations MCI East AOR. The government intends to award approximately five contracts. The contractor shall begin performance within 15 calendar days and complete it within 365 calendar days after receiving award, notice to proceed. Sealed offers are due at the place specified in item 8 by 2:00 pm hour local time **** date. The government guarantees an award amount of 5,000 to each successful offeror. The completion date for the idiq contracts is one 1 year from the date of contract award with four 4 oneyear option periods, not to exceed 60 months. The total fiveyear base and four 12month options estimated construction cost for all contracts is not to exceed 975,000,000 for the life of the contract. The government reserves the right to reject any or all proposals at any time prior to award to negotiate with any or all offerors to award the contracts to other than the offeror submitting the lowest total price to award to other than the offeror submitting the highest technically rated proposal and to award to the offeror submitting the proposal determined by the government to be the most advantageous best value to the government. Offerors are advised that award may be made without discussion or any contact concerning the proposals received. Therefore, proposals should be submitted initially on the most favorable price and technical terms. Offerors should not assume that they will be contacted or afforded an opportunity to qualify, discuss, or revise their proposals. However, the government reserves the right to clarify certain aspects of proposals or conduct discussions providing an opportunity for the offeror to revise its proposal.
The contractor shall begin performance within 15 calendar days and complete it within 365 calendar days after receiving award, notice to proceed. The contractor shall begin performance within 15 calendar days and complete it within 365 calendar days after receiving award, notice to proceed.
The government shall make progress payments monthly as the work proceeds, or at more frequent intervals as determined by the contracting officer, on estimates of work accomplished which meets the standards of quality established under the contract, as approved by the contracting officer. The government shall make progress payments monthly as the work proceeds, or at more frequent intervals as determined by the contracting officer, on estimates of work accomplished which meets the standards of quality established under the contract, as approved by the contracting officer.
Award will be made to the responsible offerors whose offer conforms to the solicitation and represents the best value to the government, price and nonprice factors considered. Award will be made to the responsible offerors whose offer conforms to the solicitation and represents the best value to the government, price and nonprice factors considered.
The government intends to evaluate proposals and award a contract without discussions with offerors except clarifications as described in ****. The government intends to evaluate proposals and award a contract without discussions with offerors except clarifications as described in ****.
If the contractor fails to complete the work within the time specified in the contract, the contractor shall pay liquidated damages to the government in the amount of see note for each calendar day of delay until the work is completed or accepted. if the contractor fails to complete the work within the time specified in the contract, the contractor shall pay liquidated damages to the government in the amount of see note for each calendar day of delay until the work is completed or accepted.
Site visit details for the seed project will be determined via amendment. Site visit details for the seed project will be determined via amendment.
The magnitude of construction for the seed project is between 10,000,000 and 25,000,000. in accordance with dfars ****, the magnitude of construction for the seed project is between 10, 000, 000 and 25, 000, 000.
