BidHits™ uses cookies to provide an individualized service and care for the privacy and protection of shared data.
By browsing this site, we understand that you agree to the terms of our Privacy Policy.
Z2FZ-- 590- 24- 450 Renovate Transitional Residences - See attached SF30 amendment ****, which extends the due date and time for offers and provides Government responses to RFIs/questions about the solicitation. See attached SF30 amendment **** which extends the due date and time for
Renovation of four transitional residences for the Hampton VA Healthcare System Renovation of four transitional residences ( TR1 at **** Stockley Gardens, Norfolk, VA ****; TR2 at 18 Roland Dr. , Hampton, VA ****; TR3 at 301 Ireland St. , Hampton, VA ****; TR4 at 22 Roland Dr. , Hampton, VA ****). Work includes general residential construction, demolition, asbestos abatement, lead- based paint removal, concrete, masonry, metals, carpentry, roofing, doors, windows, glazing, finishes, tiling, painting, fire suppression, plumbing, HVAC, electrical, fire detection and alarm, earthwork, exterior improvements, and paving.
AI helper
Renovation of four transitional residences in Hampton and Norfolk, VA. 100% SDVOSB set-aside. NAICS **** contract. Proposals due October 2, 2026, 5:30 PM ET. Site visits scheduled for September 9-10, 2026. RFIs due September 15, 2026. Performance period 365 days after notice to proceed. Bid guarantee required. Buy American requirements apply. Limitations on subcontracting certificate must be completed. Award based on lowest price technically acceptable.
The contractor shall achieve final completion within 365 calendar days after notice to proceed. As stated: achieve final completion and acceptance including final cleanup of the premises within three hundred sixtyfive 365 calendar days including submittals.
Payment will be made by the Department of Veterans Affairs Financial Services Center. The solicitation states: payment will be made by department of veterans affairs financial services center.
The award will be based on lowest price technically acceptable. As stated: the government will award a contract resulting from this solicitation to the responsible offeror whose proposal, if conforming to the solicitation, is the lowest priced technically acceptable proposal.
Offerors must be licensed general contractors and registered in SAM. As stated: the prime contractor shall be 1. a licensed general contractor operating from within the united states. . . and 2. performs work under the applicable naics code, as verified in the system for award management.
One organized site visit will be held. As stated: one 1 organized site visit will be held. Visits are scheduled for September 9-10, 2026 at the four locations.
Protests may be filed with the contracting officer or the VA. As stated: an interested party may file a protest by mail or electronically with: executive director, office of acquisition and logistics. . . or email: edprotests@va. gov.
Failure to complete the limitations on subcontracting certificate will result in rejection. As stated: failure to complete and submit vaar clause **** with the offer will result in immediate rejection of the proposal without further consideration.
Window Installation/ Hvac Installation/ Fire Alarm Installation
Z2FZ-- 590- 24- 450 Renovate Transitional Residences - See attached SF30 amendment **** which extends the due date and time for offers. Government responses to RFIs/questions about the solicitation will be issued under a separate amendment. See attached **** solicitation and i
Renovation of four transitional residences at Hampton VA Healthcare System Renovation of four transitional residences ( TR1 in Norfolk, VA; TR2, TR3, TR4 in Hampton, VA) including general residential construction, demolition, asbestos abatement, lead- based paint removal, concrete, masonry, metals, carpentry, roofing, doors, windows, glazing, finishes, tiling, painting, fire suppression, plumbing, HVAC, electrical, fire detection, earthwork, exterior improvements, and planting
AI helper
Renovation of four transitional residences for the VA Healthcare System in Hampton and Norfolk, VA. 100% SDVOSB set-aside. NAICS ****, size standard $45M. Firm-fixed-price contract. Proposals due October 2, 2026 at 5:30 PM ET via email. Site visits scheduled September 9-10, 2026. RFIs due September 15, 2026. Performance period 365 calendar days. Bid guarantee required (20% of bid or $3M, whichever less). LPTA evaluation. Must complete VAAR **** or proposal rejected. Buy American requirements apply.
Proposals are due by Friday, October 2, 2026 at 05:30pm Eastern Time. Offers shall be submitted via email to the contracting officer prior to the due date. proposals are due by friday, october 2, 2026 at 05: 30pm eastern time.
Payment will be made by the Department of Veterans Affairs Financial Services Center. payment will be made by department of veterans affairs financial services center
The award will be based on Lowest Price Technically Acceptable (LPTA). the government will award a contract resulting from this solicitation to the responsible offeror whose proposal, if conforming to the solicitation, is the lowest priced technically acceptable proposal
The prime contractor shall be a licensed general contractor operating from within the United States. the prime contractor shall be 1. a licensed general contractor operating from within the united states
If the successful bidder fails to execute contractual documents or furnish bonds within 10 days, the contract may be terminated for default. the contracting officer may terminate the contract for default
One organized site visit will be held. Site visits are scheduled for September 9 and 10, 2026 at the four locations. one 1 organized site visit will be held.
Protests filed with GAO must be served on the contracting officer, with a copy received within one day of filing. the copy of any protest shall be received in the office designated above within one day of filing a protest with the gao.
Failure to complete and submit VAAR clause **** will result in immediate rejection. failure to complete this clause will result in immediate rejection of the proposal.
Drywall Installation/ Door And Hardware Installation/ Flooring Installation/ Ceiling Installation
DOC 5JD 150 DSM ST Renovation
Interior renovation of the 5th Judicial District Department of Corrections building at 150 Des Moines Street, Des Moines, Iowa General construction, mechanical, electrical, demolition, rough carpentry, architectural wood casework, hollow metal frames, flush wood doors, service teller window units, door hardware, gypsum board assemblies, tiling, acoustical ceilings, resilient flooring, tile carpeting, interior painting, toilet and bath accessories, plumbing, HVAC, ductwork, fire alarm systems, LED lighting, sound masking system ( alternate), HVAC diffuser replacement ( alternate)
AI helper
Interior renovation of a Department of Corrections building. Bids due October 28, 2026, via IMPACS. Three bid packages: general construction, mechanical, and electrical. Additive alternates for HVAC diffuser replacement and sound masking system. Bid security of 5% required. Work hours 7am-5pm Monday-Friday. Substantial completion target April 15, 2027. Subcontractors must be identified within 48 hours of bid opening. Resident bidder preference applies. Payment retainage of 3%.
Target date to provide substantial completion is April 15, 2027. target date to provide substantial completion is april 15, 2027.
Payments are made monthly with a 3% retainage. payments will be made to the extent of the value of the work performed in the previous month less a retainage amount of 3 of the value of the work performed.
Bidders must be registered with the Iowa labor commissioner. bidder hereby certifies that the bidder is registered with the iowa labor commissioner as a contractor as required by chapter 91c, code of iowa.
Bids must remain valid for 30 days and include bid security of 5%. bidder agrees that this bid shall remain valid and shall not be withdrawn for a period of thirty 30 calendar days after the date for receipt of bids.
We selected the most helpful reviews from real users. Order may change periodically.
The idea of ​​using a keyword and sending the information by email is very good.
U. Solutions
I consistently received notifications about bids within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
G. P. da S. E. Guimaraes
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
The search engine that finds what I'm looking for just by entering keywords
J. P. L. Construccion
I like the way they provide information with the greatest possible accuracy. I love that.
M. A. Neil
All bids related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the bid documents.
R. M. Ferreira
It helps me identify areas of opportunity and find bids related to my work area.
I. J. R. Beltran
Excellent information. Just what I was looking for.
L. H. Borrelli
Excellent platform to help promote and expand the reach of your work.
C. Merino
You see a lot of tenders; you get emails with the alerts.
M. Camarasa
The email alert is amazing. I really liked the speed — the bid notices arrive by keywords directly in my inbox, which makes searching much easier. I only need to focus on the other processes, which is a big relief.
T. Santos
They update me the same day things are published, so I don’t have to check every public agency’s website.
BidHits is a government bid search engine that monitors official portals and brings relevant federal, state and local opportunities into one place. You can search on the site and receive scheduled email alerts.
Enter your email and activate the trial. For 14 days you can use the main features, including alerts and access to results. When it ends, if you do not subscribe at /subscription.php, the bid list becomes limited and you will not be charged automatically.
1) Add keywords that describe what you sell. 2) Start the trial. 3) Adjust regions, delivery times and email style after signup.
Whenever possible, yes. Some official portals require login or block direct links; in those cases we point you to the official process page so you can download the documents.
Yes. You can filter by region, procurement method, dates and value ranges. You can also save preferences for future alerts and searches.
Yes. In the dashboard you can see bids on a map and use it to plan follow-up by location.
It can happen. Smart Search uses your keywords to find related opportunities, not only exact matches. Add specific terms and remove off-topic results to improve future alerts.
Yes. You can query bids via API. Documentation at /api_integration.php. Ideal for CRM, BI and automations.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there is no auto-charge.
We monitor major official sources every day at the federal, state and local levels. New bid notices are added as soon as they are captured from the source portal.
Plans start at $ 43.00 per month, with options for different business needs and billing terms. Start with a free trial and evaluate the results before subscribing, with no automatic billing.
Add what you sell, get scheduled alerts, open documents or the official page, and use filters by region and method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the bid...
Loading summary...
Methodology
Unaided survey with 1103 active users, conducted through 10/08/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
™
