AI helper
This is a Request for Proposals (RFP) for a General Contractor for civil repairs at the Life Science Building at Sam Houston State University in Huntsville, Texas. The deadline for submission is March 5, 2026. A mandatory pre-proposal conference will be held on February 19, 2026. The owner will select the proposal that offers the best value based on the published selection criteria and on its ranking evaluation. The evaluation will be based on the respondents pricing and delivery proposal (50%) and the respondents qualifications (50%). The project includes the replacement of sidewalks, new concrete cheek wall, new area inlet, new storm sewer, and new area inlet. The contract will be awarded as a lump-sum contract. The owner reserves the right to reject any and all proposals. The project planning schedule includes key milestones such as the RFP issued, the mandatory preproposal conference, the deadline for submission of written questions, the deadline for submittal of proposals, the deadline for submittal of the hub subcontracting plan, read respondents name aloud, read respondents pricing proposal aloud, interview shortlisted firms if required, owner selects general contractor, execute general contractor agreement, notice to proceed with procurement of material, onsite construction to start, substantial completion, and final completion.
The deadline for submittal of proposals is **** 2:00 p. m. C. S. T.
The notice describes the respondents warranty and service support program for this project.
The owner will select the proposal that offers the best value based on the published selection criteria and on its ranking evaluation.
The respondents qualifications must be submitted at the same time as the execution of offer and pricing and delivery proposal.
The penalty for violation of prevailing wage rates has been increased from **** per underpaid worker per day or portion thereof to ****.
A mandatory preproposal conference will be held, and a guided tour of the project site will be included as a part of the conference agenda.