Texas Facilities Commission - 303 - Texas Comptroller Of Public Accounts - Tx - Agency Bids & RFPs

The bid notice states construction is required to commence within fourteen 14 calendar days after the notice to proceed is issued.

The bid notice states he intent of tfc is to award a contract to the vendor whose proposal is considered to provide best value to the state.

The bid notice states espondents must register for a bonfire account no charge.

The bid notice states should the respondent fail to complete the work within the contract period, including all officially approved extensions thereto, the owner has determined liquidated damages at 500 per day.

The bid notice states he site visit will be held on wednesday, january 14, 2026 at 10: 00 am.

The bid notice states he estimated construction budget for the services described in the request for proposal rfp is two million four hundred ninetyfive thousand dollars 2, 495, ****.

The designated due date will correlate with the solicitation deadline date.

Failure to return the hsp online by the designated date will result in the hsp being deemed noncompliant resulting in solicitation disqualification.

The project associated with the services requested in this solicitation is anticipated to be four hundred and sixty 460 calendar days.

Phase 2: Architecture and engineering scope of services shall include, but not be limited to, the following: f. warranty management.

It is the intent of tfc to award a contract to the respondent whose qualifications are considered to be most qualified for the services solicited in this rfq.

TFC is requesting submittal of qualifications to provide prime professional architecturalengineering ae services for project ****.

There is no site visit for this solicitation.

Deadline for submission of questions ****.

Approximate cost of construction for the aforementioned list of projects is estimated to be three million five hundred thirty thousand dollars. 3, 530, ****.

The bid notice states installation and hookup of furniture is expected to be completed under this purchase order by february 28, 2027.

The bid notice states fc shall award to the respondents whose proposal is considered to provide the best value to the state of texas as defined by tgc, section ****.

The bid notice states espondent shall be an authorized dealer of proposed manufacturers furnishings, with prior project experience in project management, ordering, installing, and servicing systems furniture.

The bid notice states contractors failure to complete the work within the contract time as required will cause damage to owner. these damages shall be liquidated by agreement of contractor and owner, in the amount of **** per day as set forth in the purchase order.

The bid notice states attendance of at least one 1 of the two 2 scheduled preproposal teleconferences is mandatory.

The bid notice states deadline for submission of questions ****.

The bid notice states he estimated budget for the furniture, furnishing and associated installation described in the rfp is fifteen million dollars 15, 000, 000.

The services requested in this solicitation are required to commence within fourteen 14 calendar days of delivery of a notice to proceed. services undertaken pursuant to this rfq will be required to commence within fourteen 14 calendar days of delivery of a notice to proceed.

The AE services shall include warranty management. q. warranty management.

The contract will be awarded to the respondent whose qualifications are considered to be most qualified for the services solicited in this rfq. 1. it is the intent of tfc to award a contract to the respondent whose qualifications are considered to be most qualified for the services solicited in this rfq.

The evaluation committee will evaluate and score each submittal based on company information, relevant experience and qualifications, proposed methodology, quality assurance/quality control, litigation history, and the HUB subcontracting plan. 4. the evaluation committee will evaluate and score each submittal based on the following criteria: criteria weight company information pass/fail relevant experience and qualifications 50 points proposed methodology 40 points quality assurance/quality control 10 points litigation history pass/fail hub subcontracting plan pass/fail total 100 points

An optional site visit will be conducted for this solicitation on Thursday, December 11th at 10:00 am. 3. site visit optional: an optional site visit will be conducted for this solicitation on thursday, december 11th at 10:00 am.

The deadline for submission of questions is December 16, 2025. deadline for submission of questions ****

The approximate cost of construction for the project is estimated to be eighty-five million dollars 85,000,**** cost of construction for the project is estimated to be eightyfive million dollars 85, 000, 000 to kick off the project.