Gen. Land Off. & Vet. Land Bd. - 305 - Texas Comptroller Of Public Accounts - Tx - Agency Bids & RFPs

The deadline for submission of solicitation responses is May 26, 2026, at 2:00 p. m. CT.

The bid notice does not explicitly detail payment terms beyond mentioning the Prompt Pay Act and retainage of five percent (5%) of each application for payment.

The bid notice does not explicitly detail warranty terms beyond mentioning that the contract continues in force and effect until the expiration of all warranty periods described in the Uniform General Conditions or other contract document.

The GLO will make an award to the respondent that provides the best value to the state of Texas, determined by a weighted scoring methodology including cost, demonstrated relevant experience, qualifications and past performance, technical proposal, and safety record, quality control program and cost controls.

Respondents must have recently been in the coastal construction business for a minimum of five (5) years, or the principals/owners must have had ownership/executive management experience in a previous company that provided coastal construction services for a minimum of five (5) years. They must also have demonstrated relevant experience in meeting completion dates and construction schedules, and in excavation, hauling, and placement of fill in shallow water environments for projects of similar scope and size.

If contractor fails to achieve substantial completion within the contract time, contractor shall be liable to the GLO for liquidated damages of **** per day until the contractor achieves substantial completion.

Respondent is strongly encouraged to visit the site and assess the work to be performed before submitting a proposal.

Any respondent unsuccessful or aggrieved in connection with this solicitation may file a protest in accordance with title 31, section 3. 50 of the Texas Administrative Code.

The approximate cost range for construction of the project is $250,**** to $300,****.

The deadline for submission of solicitation responses is May 7, 2026, at 2:00 p. m. CDT.

Invoices must be submitted to ***@***. *. * and will be paid in accordance with the Prompt Pay Act, provided they comply with the contract terms.

Provider warrants that it will perform all services under this contract in a manner consistent with the degree of care and skill ordinarily exercised by members of the same profession currently practicing under similar circumstances.

The GLO shall not be obligated to accept the lowest priced proposal but shall make an award to the respondent that provides the best value to the state of Texas.

Respondents must have recently been in the data analytics services business for a minimum of three years within the last five years, or the principals/owners must have had recent ownership/executive management experience in a previous company that provided data analytics services for a minimum of three years within the last five years.

The bid notice does not require sample submissions.

Any respondent unsuccessful or aggrieved in connection with this solicitation may file a protest in accordance with 31 TAC 3. 50.

The estimated total value is not specified in the bid notice.

The deadline for submission of qualifications is April 30, 2026, at 2:00 p. m. CT.

The bid notice does not explicitly detail payment terms beyond referencing the Prompt Pay Act and invoice submission requirements.

The bid notice does not explicitly detail warranty requirements.

The GLO shall make an award to the respondent that provides the best value to the State of Texas for each specific project identified by the GLO.

Respondents must have recently been in the marine services business for at least 5 years, or the principals/owners must have had ownership/executive management experience in a previous company that provided similar services for a minimum of five years. They must also have demonstrated relevant experience in complying with project schedules and budgets, and in sunken vessel services within the last five years. Additionally, respondents must be registered with SAM. gov with an active UEID or the ability to obtain one prior to contract execution.

If a project is not completed by the date specified in the work order, a penalty amount of no more than $500 per day shall be forfeited from the overall payment of the work order. In the event of a natural disaster, this penalty shall not be enforced, and a secondary due date will be issued.

The bid notice does not mention a site visit.

The bid notice does not mention sample submission.

The bid notice does not explicitly state a challenge deadline, but it does mention that any respondent unsuccessful or aggrieved in connection with this solicitation may file a protest in accordance with title 31, 3. 50 of the Texas Administrative Code.