The University of Texas at Austin is seeking competitive sealed proposals for the MSH BRK Apt Phase 12 upgrade at Brackenridge Apartments. The project involves renovating existing married student housing buildings. The budget range for the project is approximately $2,500,**** to $2,800,****. The project schedule is to complete the project prior to 150 calendar days from issuance of notice to proceed. The deadline for submission no. 1 is **** at 11:00 a. m. , submission no. 2 is **** at 11:00 a. m. , and submission no. 3 is **** at 11:00 a. m. A preproposal conference will be held on **** at 10:00 a. m. and an initial site visit will be held on **** at 1:00 p. m. The successful respondent will be required to enter into the latest version of the contract in the form included in this rfp. Award shall be made to the respondent offering the best value to the owner based on the requirements of the rfp. The respondents selected will be the respondents whose qualifications, as presented in the response to this rfp, are the most advantageous and offer the best value to the university. All properly submitted proposals will be reviewed, evaluated and ranked by the owner. The respondents selected will be the respondents whose qualifications, as presented in the response to this rfp, are the most advantageous and offer the best value to the university. All properly submitted proposals will be reviewed, evaluated and ranked by the owner. The criteria for evaluation of proposals, and selection of the qualified respondents, will be based on the factors listed below: proposed cost set forth in section 7 maximum number of points awarded: 30. evaluation of qualifications based on responses to evaluation criteria included in section 8 maximum number of points awarded: 70.
The project schedule is to complete the project prior to 150 calendar days from issuance of notice to proceed. The project schedule is to complete the project prior to 150 calendar days from issuance of notice to proceed.
The university will, within thirty 30 calendar days from the date an acceptable application and supporting documentation for payment is received, approve or disapprove the amount reflected in such application and if the university approves such amount or any portion of such amount, promptly pay the amount so approved, provided contractor is not in breach of or in default under any agreement resulting from this rfp. The university will, within thirty 30 calendar days from the date an acceptable application and supporting documentation for payment is received, approve or disapprove the amount reflected in such application and if the university approves such amount or any portion of such amount, promptly pay the amount so approved, provided contractor is not in breach of or in default under any agreement resulting from this rfp.
The awarded respondent shall promptly supply a payment bond as well as a performance bond if the maximum possible award is over 100, **** in the full amount of the awarded contract. The awarded respondent shall promptly supply a payment bond as well as a performance bond if the maximum possible award is over 100, **** in the full amount of the awarded contract.
Award shall be made to the respondent offering the best value to the owner based on the requirements of the rfp. Award shall be made to the respondent offering the best value to the owner based on the requirements of the rfp.
The respondents selected will be the respondents whose qualifications, as presented in the response to this rfp, are the most advantageous and offer the best value to the university. The respondents selected will be the respondents whose qualifications, as presented in the response to this rfp, are the most advantageous and offer the best value to the university.
Liquidated damages shall run until the project is completed. Liquidated damages shall run until the project is completed.
A site visit will be held immediately afterwards. A site visit will be held immediately afterwards.
The deadline for questionsrequests for clarification is **** at noon. The deadline for questionsrequests for clarification is **** at noon.
The budget range for the project is approximately $2,500,**** to $2,800,****. The budget range for the project is approximately $2,500,**** to $2,800,****.
