BidHits™ uses cookies to provide an individualized service and care for the privacy and protection of shared data.
By browsing this site, we understand that you agree to the terms of our Privacy Policy.
City Of Brookside Village - M2142 - Texas Comptroller Of Public Accounts - Tx - Agency Bids & RFPs
Government bid alerts, regional filters, and fast access to documents
90% recommend BidHits™ (1065 real users, 06/23/2026).Methodology
EXCLUSIVE MUNICIPAL SOLID WASTE DISPOSAL AND RECYCLING - THE City of Brookside Village intends to engage a Contractor to exclusively collect, legally dispose and process solid waste, bulky and brush waste, with an individual option of recyclable materials from all single- family homes ( Customer) and City facilities. All single- family homes have mandatory inclusion and shall be charged as described for services provided in the contract. Commercial and industrial customers are not included in this contr
exclusive municipal solid waste disposal and recycling The city of brookside village intends to engage a contractor to exclusively collect, legallydispose and process solid waste, bulky and brush waste, with an individual option of recyclablematerials from all singlefamily homes customer and city facilities. all singlefamily homeshave mandatory inclusion and shall be charged as described for services provided in thecontract. commercial and industrial customers are not included in this contract but may havethe option to become a customer if they so choose. commercial customers may choose anyprivate firm for the collection, transportation, processing, andor disposal of solid waste andrecyclable materials that best meets their budgetary restrictions.
AI helper
The City of Brookside Village is seeking a contractor for exclusive solid waste disposal and recycling services. Bids are due March 30, 2026. The contract will be for five years with the possibility of two one-year extensions. The contractor must provide residential curbside collection twice a week and recycling once a week. The city will evaluate proposals and award the contract on or after April 1, 2026. The contractor must provide insurance and a performance bond. The contractor will be responsible for sending invoices directly to residents. The contract will require performance in Brazoria County, Texas and any, and all litigation shall be filed in same county. Texas law shall apply to the contract.
The bid notice states wice weekly collection of solid waste, excluding observed holidays.
The bid notice states he contractor shall send all invoicing directly to individual residents or commercial businessesof the city of brookside village for payment.
The bid notice states considerations will include: costprice, lowest responsible bid considering longterm value 40 experience and references, track record in city contracts 25 service plan quality, twice weekly schedule and innovations 20 financial stability and capacity, ability to perform without interruption 15
The bid notice states he opening of the bid shall not be construed as an acceptance of the contractor as a qualified, responsible contractor.
The bid notice states if contractor fails to meet the performance standard, the city reserves the right to establish penalties not meeting the expected performance metrics
City of Brookside Village Request For Qualifications for Design- Build Services - The CITY OF BROOKSIDE VILLAGE is soliciting a request for qualifications ( RFQ) for Design- Build Services of a new Brookside Village City Barn/Public Works Bldg. project at City of Brooskide Village, Texas. The CITY OF BROOKSIDE VILLAGE will solicit and accept responses to the RFQ until 11: 00AM local time, Friday, October 10, 2025 . The CITY OF BROOKSIDE VILLAGE will qualify a maximum of three respondents that submit pro
Request for Qualifications for Design- Build Services for the new Brookside Village City Barn Public Works Bldg.
AI helper
The City of Brookside Village is seeking qualifications from design-build firms for the construction of a new city barn. Responses are due October 10, 2025, at 11:00 AM local time at City Hall. The project is estimated to cost approximately $500,****, depending on the design. The project must be substantially completed by October 1, 2026. A maximum of three respondents will be selected to submit proposals. The complete RFQ package is available via email or telephone. The selection process will consider experience, technical competence, capability, and past performance. Insurance and certifications are required. The project site is located at **** Welborn Rd. , Brookside Village, TX ****.
Responses to the RFQ must be received no later than 11:00 AM, October 10, 2025, at the City of Brookside Village City Hall.
The city will utilize weighted selection criteria for experience, technical competence, capability, and past performance of the proposer/design-build team.
A maximum of three respondents will be selected to submit proposals and interview.
Failure to complete the work on time and obtain a certificate of occupancy will result in substantial penalties to the design-build firm.
The design and construction budget for this work will range to $500,****, depending on the design tendered.
Brookside Village City Barn/Public Works Bldg. - CITYOF BROOKSIDE VILLAGE NOTICE TO BIDDERS Request for Qualifications Design- Build Services The City of Brookside Village is requesting qualifications for Design- Build Services per Texas Government Code Chapter2267, Subchapter G for the new Brookside Village City Barn/Public Works Bldg. Project. Responses will be received at City Hall Brookside Village, **** Brookside Rd. , Brookside Village, Texas **** until 11: 00 AM local time, Friday, October 3, 2
Request for Qualifications for Design- Build Services for the new Brookside Village City Barn Public Works Bldg.
AI helper
The City of Brookside Village is seeking qualifications from design-build firms for the construction of a new city barn. Responses are due October 3, 2025, at 11:00 AM local time, at City Hall. A maximum of three respondents will be selected to submit proposals. The project is estimated to cost approximately $500,****, depending on the design. Completion is required by October 1, 2026. The selection process will consider experience, technical competence, capability, and past performance. Submittals must include completed forms (conflict of interest, W9, felony conviction). Insurance coverage is required. The project site is located at **** Welborn Rd. , Brookside Village, TX 77581. The city reserves the right to reject any or all proposals.
Responses must be received no later than 11:00 AM, October 3, 2025, at the City of Brookside Village City Hall, **** Brookside Rd. , Brookside Village, Texas ****. If mailed, it is not considered received until actually received by the city.
The city will utilize the following weighted selection criteria: experience of proposer/design-build team (20 points), technical competence of proposer/design-build team (25 points), capability of proposer/design-build team (35 points), and past performance of proposer/design-build team (20 points). The city will select the offer that provides the best value.
The city will qualify a maximum of three respondents to submit proposals. Respondents must provide a valid email address.
Failure to complete the work on time and obtain a certificate of occupancy will result in substantial penalties to the design-build firm.
The design and construction budget for this work will range to $500,****, depending on the design tendered.
RFQ - ENGINEERING DESIGN SERVICES - BROOKSIDE VILLAGE CITY BARN/PUBLIC WORKS BUILDING PROJECT - CITY OFBROOKSIDE VILLAGE NOTICE TO BIDDERS REQUEST FOR QUALIFICATIONS - ENGINEERING DESIGN SERVICES The City of Brookside Village isrequesting qualifications for an engineer to assist in the design of a newBrookside Village City Barn/Public Works Building Project. Responses willbe received at City of Brookside Village City Hall, **** Brookside Rd. , BrooksideVillage, Texas **** on Tuesday, June 17 , 20
Request for Qualifications for Design- Build Services for the new Brookside Village City Barn Public Works Bldg.
AI helper
The City of Brookside Village is seeking qualifications from design-build firms for the construction of a new 3,360 sq ft City Barn Public Works Bldg. Responses are due August 30, 2024, at 12:00 PM local time, at City Hall. A maximum of three respondents will be selected to submit proposals. Selection criteria include experience, technical competence, capability, and past performance. The project must be substantially completed by October 1, 2025. Required documents include a Conflict of Interest Questionnaire, W9 form, felony conviction form, and proof of insurance. The project site is located at **** Welborn Rd. , Brookside Village, TX **** must comply with Texas Government Code chapters **** and ****, including advertising and receiving proposals from qualified subcontractors and suppliers. The city reserves the right to reject any or all proposals and to waive any informality.
Add keywords for your products or services. Smart Search helps catch related opportunities beyond exact matches.
2
Start the trial and receive alerts
Use the 14-day free trial and get email alerts with documents or official posting links.
3
Tune your feed
Adjust keywords, regions, email schedule and email style. Use map view and filters when you want to explore.
What our users say
All bids related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the bid documents.
R. M. Ferreira
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
The tool is truly effective at scanning bid documents, efficiently delivering bids.
BidHits™ is a government bid search engine that monitors official portals and brings relevant federal, state and local opportunities into one place. You can search on the site and receive scheduled email alerts.
Enter your email and activate the trial. For 14 days you can use the main features, including alerts and access to results. When it ends, if you do not subscribe at /subscription.php, the bid list becomes limited and you will not be charged automatically.
1) Add keywords that describe what you sell. 2) Start the trial. 3) Adjust regions, delivery times and email style after signup.
Whenever possible, yes. Some official portals require login or block direct links; in those cases we point you to the official process page so you can download the documents.
Yes. You can filter by region, procurement method, dates and value ranges. You can also save preferences for future alerts and searches.
Yes. In the dashboard you can see bids on a map and use it to plan follow-up by location.
It can happen. Smart Search uses your keywords to find related opportunities, not only exact matches. Add specific terms and remove off-topic results to improve future alerts.
Yes. You can query bids via API. Documentation at /api_integration.php. Ideal for CRM, BI and automations.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there is no auto-charge.
We monitor major official sources every day at the federal, state and local levels. New bid notices are added as soon as they are captured from the source portal.
Plans start at $ 43.00 per month, with options for different business needs and billing terms. Start with a free trial and evaluate the results before subscribing, with no automatic billing.
Add what you sell, get scheduled alerts, open documents or the official page, and use filters by region and method.
Transcript
Welcome to BidHits™.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits™ shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits™ now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the bid...
Loading summary...
Methodology
Unaided survey with 1065 active users, conducted through 06/23/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
