The Texas Facilities Commission (TFC) is requesting proposals for the provision of furniture and fixtures for the **** Congress and **** Lavaca state office buildings in Austin, TX. The deadline for proposal submission is January 27, 2026, at 3:00 PM. A mandatory preproposal teleconference is scheduled for December 16 and 17, 2025. Installation and hookup of furniture is expected to be completed by February 28, 2027. A bid bond is required. The estimated budget is $15,000,000. A Hub Subcontracting Plan is required. A full-scale mockup workstation is required as part of the interview process.
The bid notice states installation and hookup of furniture is expected to be completed under this purchase order by february 28, 2027.
The bid notice states fc shall award to the respondents whose proposal is considered to provide the best value to the state of texas as defined by tgc, section ****.
The bid notice states espondent shall be an authorized dealer of proposed manufacturers furnishings, with prior project experience in project management, ordering, installing, and servicing systems furniture.
The bid notice states contractors failure to complete the work within the contract time as required will cause damage to owner. these damages shall be liquidated by agreement of contractor and owner, in the amount of **** per day as set forth in the purchase order.
The bid notice states attendance of at least one 1 of the two 2 scheduled preproposal teleconferences is mandatory.
The bid notice states deadline for submission of questions ****.
The bid notice states he estimated budget for the furniture, furnishing and associated installation described in the rfp is fifteen million dollars 15, 000, 000.
