Texas State Library - 306 - Texas Comptroller Of Public Accounts - Tx - Agency Bids & RFPs

The bid notice states deliverables may be negotiated, but all services must be completed at the end of the agencys fiscal year.

The bid notice states payment will be provided upon satisfactory performance of the requested services per the negotiated deliverables schedule in section ii of this solicitation.

The bid notice states slac intends to award a single contract to the one 1 respondent whose proposal is determined to provide the best value to the state, in accordance with the evaluation criteria outlined in this solicitation.

The bid notice states espondent shall meet the following minimum qualifications and experience to be eligible for consideration.

The response is due on August 21, 2025, at 2:00 PM CT. esponse due date: **** 2: 00 pm ct

Payment will be provided for products and related services after the project is completed satisfactorily. Incomplete punch list items will delay payment. Payment normally will be made to the contractor within 30 days after receipt of a properly prepared invoice or the receipt of and the acceptance of products and/or services ordered whichever is later. his is a turnkey project, which means payment will be provided for products and related services after the project is completed satisfactorily. incomplete punch list items will delay payment. the contractor will provide an invoice upon completion of the project. payment normally will be made to the contractor within 30 days after receipt of a properly prepared invoice or the receipt of and the acceptance of products and/or services ordered whichever is later.

Respondents' submission is evaluated and scored on a weighted system to determine the best value. evaluation criteria: respondents submission is evaluated and scored on a weighted system to determine the best value as follows: administrative review minimum submission requirements passfail initial evaluation criteria weight vendor experience 35 vendor equipment and staff 25 vendor timelines 35 vendor offered warranty terms 5 total 100 final evaluation criteria vendor references passfail technical proposal 50 pricing analysis 50 total 100

Respondents shall have available the necessary qualified personnel, skills, organization and facilities, equipment, and supplies to fulfill the requirements under this solicitation and any resulting contract. Respondents shall be in good financial standing. TSLAC reserves the right to request a copy of the respondents audited or unaudited financial statements. espondent shall have available the necessary qualified personnel, skills, organization and facilities, equipment, and supplies to fulfill the requirements under this solicitation and any resulting contract. 6. 1. 3. respondent shall be in good financial standing. tslac reserves the right to request a copy of the respondents audited or unaudited financial statements.

Respondents should contact Fred Huber at 512 **** to schedule attendance and confirm driving directions. espondents should contact fred huber at 512 **** to schedule attendance and confirm driving directions. respondents are encouraged to provide at least two 2 days advance notice to schedule attendance.