Jersey City Redevelopment Agency - Nj - Agency Bids & RFPs

The project work shall be completed within 365 calendar days of the contractor's receipt of written notice to proceed. the project work shall be completed within 365 calendar days of the contractors receipt of written notice to proceed.

A maintenance bond is required, guaranteeing against defective quality of work or materials for a period of two years. the contractor shall supply a maintenance bond in the amount not to exceed of 100 of the final contract amount guaranteeing against defective quality of the work and or materials for the period of two 2 years.

The contract will be awarded to the lowest, responsible, responsive bidder. the owner will award a contract to the lowest, responsible, responsive bidder

Bidders must be prequalified under the New Jersey Division of Property Management and Construction (DPMC) C024 Historical Restoration classification. all bidders are required to be prequalified under the dpmc c024 historical restoration classification.

Liquidated damages of $1,000 per working day for delay. the contractor shall pay the owner 1, **** per working day for each day that expires after the time specified in this agreement until performance of the work is complete.

A mandatory prebid conference/site tour is scheduled for October 15, 2026 at 11:00 AM. a mandatory prebid conferencesite tour is scheduled for thursday, october 15, 2026 at 11: 00a. m.

Challenges to bid specifications must be filed no less than three business days prior to bid opening. any prospective bidder who wishes to challenge a bid specification, shall file such challenges in writing with the project manager with a copy to the owners representative no less than three 3 business days prior to the opening of the bid.

Bids received after the specified date and time will be returned unopened. any bid received after the date and time specified will be returned, unopened to the bidder.

Qualification statements must be received by 11:00 a. m. prevailing time on November 6, 2026. qualification statements must be received by the agency no later than 11: 00 a. m. prevailing time on november 6, 2026

Evaluation considers which are the most advantageous, price and other factors considered including quality, experience, knowledge, price proposal, staffing, and other factors.

Respondents must demonstrate professional, financial, and administrative capabilities. the agency will consider qualification statements only from respondents that. . . have demonstrated the capability and willingness to provide high quality services

Incomplete or non-responsive qualification statements may be rejected. the agency reserves the right. . . to reject any respondent that submits incomplete responses to this rfq, or a qualification statement that is not responsive to the requirements

Qualification statements must be received by the agency no later than 11:00 a. m. prevailing time on October 9, 2026. must be received by the agency no later than 11:00 a. m. prevailing time on october 9, 2026

Qualification statements will be evaluated as to which are the most advantageous, price and other factors considered. evaluated by the agency as to which are the most advantageous, price and other factors considered

Respondents must demonstrate professional, financial and administrative capabilities. possess the professional, financial and administrative capabilities to provide the proposed services

Qualification statements not received by the deadline will be rejected. any and all qualification statements not received by the agency by 11:00 a. m. prevailing time on october 9, 2026, will be rejected

The agency will evaluate proposals based on their completeness, feasibility, responsiveness to the rfp requirements and redevelopment goals described herein, strength of the development approach, innovation of the proposal, and respondents comparable past experience and capacity to successfully complete the proposed project.

Respondents must submit a detailed proposal, including a background section detailing their experience and business organization type.

There will be one site visit conducted on October 7, 2026, at a time to be determined at 350 Washington Street and then at 80 Bay Street.

Questions should be directed to: robert napiorski via email at ***@***. *. *, with a copy to bethany russo via email at ***@***. *. * written questions submitted by email for interpretation will be considered. such questions will only be accepted until October 27, 2026 at 12:00 p. m. noon est.

Any respondent found violating the above will be disqualified from consideration.

The agency will evaluate proposals based on their completeness, feasibility, responsiveness to the rfp requirements and redevelopment goals described herein, strength of the development approach, innovation of the proposal, and respondents comparable past experience and capacity to successfully complete the proposed project.

Questions should be directed to: yesenia palacios via email at ***@***. *. *, with a copy page 3 the beacon redevelopment area to shoshana schiff, esq. , via email at ***@***. *. * questions accepted until october 13, 2026 at 12:00 p. m. noon est.

Any respondent found violating the above will be disqualified from consideration.