Murfreesboro City Bids, TN

The estimated delivery date after receipt of order (ARO) needs to be provided by the vendor.

A one-year warranty is included to cover all malfunctions and routine maintenance that cannot be performed by operating staff for the first year after installation.

Respondents must provide a tailored capability statement indicating the firm's ability to provide the product and related services, along with their unique entity identifier (UEI) number, organization name, address, point of contact, and size/type of business.

The vendor must visit the site to verify space, electrical, and plumbing requirements. vendor must visit site to verify space, electrical, and plumbing requirements.

Questions and information that are not provided shall be considered nonresponsive to the request for information and the contractor shall not be considered as part of the market research.

The performance period is 540 calendar days. The first 360 days are for acquisition of electrical equipment and preconstruction activities, with the remaining 180 days for phased installation. Construction shall not begin until all equipment is on hand.

Payment will be made by electronic invoicing. Invoices must be submitted electronically. Payment for materials stored offsite is not authorized unless approved by the CO.

Award will be made to the responsible SDVOSB offeror whose proposal conforms to the solicitation and is most advantageous to the government, price and other factors considered, using the Lowest Price Technically Acceptable (LPTA) process.

Offerors must be registered in SAM. gov and SBA DSBS. They must demonstrate relevant construction experience, key personnel experience, and satisfactory past performance. Joint ventures must also submit SBA DSBS registration or certification.

The contract may be terminated for default if the contractor fails to execute contractual documents or furnish executed bonds within 10 days after award notification. Liquidated damages may apply in the event of a data breach or privacy incident involving sensitive personal information.

A site visit is mandatory on July 10, 2026, at 10 am ET, meeting in the lobby of the Troy Bowling Campus. here will only be one 1 site visit for this project.

Protests must be filed with the contracting officer or the Executive Director, Office of Acquisition and Logistics, Risk Management and Compliance Service. The copy of any protest shall be received in the office designated above within one day of filing a protest with the gao.

Failure to submit required documentation, such as bid bonds, SAM registration, SBA DSBS proof, or **** reports, can lead to disqualification. Also, failure to meet technical requirements or provide accurate information can result in ineligibility for award.

The magnitude of construction is between $5,000,**** and $10,000,****.

The contract period for the base year is from 10/01/2026 to 09/30/2027. Option periods extend through 09/30/2031.

Payment will be made by electronic funds transfer. Invoices shall be submitted monthly and must include specific details such as contractor name, invoice date, contract number, date of service, hourly rate, and total price. Invoices must be submitted electronically to the tungsten website at www. ***. *. *

Contractors physicians must be board-certified by the American Board of Psychiatry and Neurology and currently certified in BLS and ACLS. They must possess a current, full, and unrestricted license to practice medicine in any U. S. state, territory, or commonwealth. All contractors physicians shall be board certified by the american board of psychiatry and neurology www. ***. *. *

If contracted services do not meet quality and/or safety expectations, remedies may include a performance improvement plan, increased monitoring, consultation or training, replacement of personnel, or contract termination.

The government reserves the right to refuse acceptance of any contractor personnel if personal or professional conduct jeopardizes patient care or interferes with facility operations. Breaches of conduct include intoxication, theft, patient abuse, or dereliction of duty.

The contract minimum guarantee is $15,000. 00. The total contract ceiling maximum is TBD at the time of award.

Respondents must ensure their response is complete and sufficiently detailed to allow the government to determine the organization's qualifications to perform the work. Any organization responding to this notice should ensure that its response is complete and sufficiently detailed to allow the government to determine the organizations qualifications to perform the work.