Competitive small business set-aside for repair of taxiways Alpha and Bravo at North Auxiliary Airfield, SC. Sealed offers due 12:00 PM local time on 02 Dec 2026. Performance begins within 60 calendar days and completes within 172 calendar days after notice to proceed. Proposal bond required at 20% of proposal price; performance and payment bonds at 100% each. Preproposal conference and site visit scheduled for 4 Nov 2026 at 10:30 AM EST. Questions deadline 12 Nov 2026 at 9:00 AM EST. Funds not presently available; award subject to availability. NAICS ****, size standard $45M.
Performance must begin within 60 calendar days and complete within 172 calendar days after receiving award, notice to proceed. the contractor shall begin performance within 60 calendar days and complete it within 172 calendar days after receiving award, notice to proceed.
Progress payments are made monthly as work proceeds, based on estimates approved by the contracting officer. the government shall make progress payments monthly as the work proceeds, or at more frequent intervals as determined by the contracting officer.
The solicitation uses tradeoff procedures. this solicitation is issued as a competitive small business setaside using tradeoff procedures.
Offerors must be small business concerns under NAICS **** with size standard of $45,000,**** annual receipts. naics code: **** size standard: 45, 000, ****
Liquidated damages of $659 per calendar day of delay until work is completed or accepted. the contractor shall pay liquidated damages to the government in the amount of 659 for each calendar day of delay.
A preproposal conference and site visit is scheduled for 4 November 2026 at 10:30 AM EST. a preproposal conference and site visit is scheduled for 4 november 2026 at 10: 30 am est.
The deadline for all questions pertaining to this solicitation is 12 November 2026 at 9:00 AM EST. the deadline for all questions pertaining to this solicitation will be 12 november 2026 at 9: 00am est.
Offers providing less than 15 calendar days for government acceptance after the due date will be rejected. offers providing less than 15 calendar days for government acceptance after the date offers are due will not be considered and will be rejected.