Sealed bids are invited for the supply of high range waterway nozzles for KFD. Bids are due by Thursday, June 18, 2026, at 9:45 a. m. Bid opening will be on the same day at 10:00 a. m. Bidders must email questions no later than five working days prior to bid opening to ***@***. *. * bids must be written in ink or typewritten and signed. The City of Kenner reserves the right to award to the lowest responsive bidder. Freight charges should be included in the total cost. Estimated quantities are for bidding purposes only. Bids may not be withdrawn for 45 days after the closing date. The agreement amount will not exceed $65,**** will be made upon completion and acceptance. Contractor shall invoice Kenner within 40 days of services/materials billed for.
Sealed bids will be received until Thursday, June 18, 2026, by 9:45 a. m. Sealed bids will be received until thursday, june 18, 2026 by 9: 45 a. m.
Payment will be made only upon completion and acceptance by Kenner. Contractor shall invoice Kenner upon such completion and acceptance. Payment will be made only upon completion and acceptance by kenner. Contractor shall invoice kenner upon such completion and acceptance by email to purchasing@kenner. la. us.
The City of Kenner reserves the right to award contracts or place orders with the lowest responsive bidder, on a lump sum or individual item basis or such combination as shall in its judgment be in the best interest of the city. Awards will be based on compliance with the specifications and the delivery and/or completion date. he city of kenner reserves the right to award contracts or place orders with the lowest responsive bidder, on a lump sum or individual item basis or such combination as shallin its judgment be in the best interest of the city. awards will be based on compliance with thespecifications and the delivery andor completion date.
Kenner will consider compliance with the prescribed requirements, the qualifications of the bidders, and price to determine the lowest responsive and responsible bidder for award. kenner will consider compliance with the prescribed requirements, thequalifications of the bidders, and price to determine the lowest responsive and responsible bidder for award.
The bidder certifies that they have personally inspected and are familiar with the project site. has personally inspected and is familiar with the project site
Bid may be disqualified if not quoted fob delivered or if freight charges are not indicated on bid form. bid may be disqualified ifnot quoted fob delivered or if freight charges are not indicated on bid form.
The agreement amount will not exceed $65,****. his agreement will not exceed 65, ****.
