Burs Government Bids & RFPs

Bids must be received by 11:00 a. m. on Tuesday, September 1, 2026, at the office of the city clerk.

The contract documents call for monthly progress payments based upon the percentage of the work completed.

The contractor shall provide a written guarantee that the work will remain free of defects and suitable for its intended use for the period required by the contract documents or the longest period permitted by the law of this state, whichever is longer.

The city shall award the contract to the lowest responsive, responsible bidder as determined by the city from the base bid alone.

All bidders must possess proper licenses for performance of this contract, and subcontractors must possess the appropriate licenses for each specialty subcontracted.

The contractor will pay the city the sum set forth in special conditions, article 1. 11 for each and every calendar day of delay beyond the time prescribed in the contract documents for finishing the work, as liquidated damages.

Each bidder shall visit the site of the proposed work and fully acquaint itself with the conditions relating to the construction and labor required so that the bidder may fully understand the work.

Bidders may file a protest of a bid with the city's public works services director in writing within five calendar days after the bid opening date.

Failure to comply with labor compliance requirements, such as not maintaining active registration with the department of industrial relations, may render the bid nonresponsive.

Payments will be paid in accordance with the state prompt payment act and rules when applicable. payments, including late payment charges, will be paid in accordance with the state prompt payment act and rules when applicable.

Vendor warrants that supplies will be free from defects for a period of twelve months or longer if so specified in writing. be merchantable, of good quality and workmanship, and free from defects for a period of twelve months or longer if so specified in writing,

Vendor must be a tier 1 or tier 2 internet provider and have a valid service provider identification number (SPIN) from the universal service funds schools and libraries program. vendor must be a tier 1 or tier 2 internet provider.

Service credits are provided to compensate DOIT for any service failures per service level agreement (SLA). vendor must provide service credits to compensate doit for any service failures per service level agreement sla that will become part of the contract.

Failure to complete and upload vendor disclosure or IPG active registered vendor disclosure will result in disqualification. failure to complete and upload will result in disqualification

The delivery schedule varies by line item, with lead times of 5, 6, or 6 weeks from the date of award. For the first article, the lead time is 6 weeks. delivery schedule 350 each ship to from date of lead time dodaac: ****

The contract incorporates FAR clause **** for wide area workflow payment instructions. wide area workflow payment instructions jan 2023

The government intends to evaluate all timely quotes received from eligible vendors on a lowest price technically acceptable basis. the government intends to evaluate all timely quotes received from eligible vendors on alowest price technically acceptable lpta basis.

The contractor must maintain a quality system adhering to ISO ****:**** standards. the contractor shall maintain a quality system which adheres, at minimum, to the requirements of iso ****: **** standards.

A first article sample of 20 burst plugs and 20 burst plug covers must be submitted prior to the first delivery. The contractor shall submit a first article sample of 20 burst plugs and 20 burst plug covers prior to the first delivery of any production hardware.

Failure to deliver any first article on time, or if the contracting officer disapproves any first article, will constitute a failure to make delivery within the meaning of the default clause. if the contractor fails to deliver any first article on time, or the contracting officer disapproves any first article, the contractor will have failed to make delivery within the meaning of the default clause of this contract.

The contractor shall notify the contracting officer 30 days in advance if the contractor cannot meet the contract delivery schedule. The contractor shall notify the contracting officer 30 days in advance if the contractor cannot meet the contract delivery schedule.

Bids must be submitted by August 13, 2026, at 2:00 p. m. at Albany City Hall. bid submission. city of albany city will accept sealed bids for its 2026 sanitary sewerand storm drain rehabilitation project project, by or before august 13, 2026, at 2: 00p. m.

Bidders must hold a valid California Class A General Engineering Contractor license and be registered with the Department of Industrial Relations. this project requires a valid california contractors license for thefollowing classifications: class a general engineering contractor.

A nonmandatory bidders conference will be held on July 27, 2026, at 2:00 pm at the Albany Public Works Building. a bldders conference will be held on july 27, 2026at 2: 00 pm, for the purpose of acquainting all prospective bidders with the contractdocuments and the worksite.

The city may not accept a bid proposal without proof that the bidder is registered with the California Department of Industrial Relations. city may not accept a bid proposal from or enter into thecontract with a bidder, without proof that the bidder is registered with the californiadepartment of industrial relations dir to perform public work under laborcode section ****.

The estimated construction cost is 1,960,000. the estimated construction cost is 1, 960, 000.