The contractor shall repair the roof for the garage/shop building at the US Fish Wildlife Office in Red Bluff, CA. The scope includes installing new roof vents and flashing, and replacing hip, rake, and ridge flashing. Performance is expected to commence within 30 days of contract signing and complete within 90 calendar days after award. Payment will be made upon completion of the work and receipt of the invoice. The contractor must adhere to various federal clauses regarding labor standards, environmental protection, and safety.
Payment will be made upon completion of the work consistent with the terms of the contract and receipt of the invoice. payment will be made upon completion of the work consistent with the terms of the contract and receipt of the invoice.
The contractor shall provide warranty details for all installed and replaced roofing materials. provide warranty details for all installed and replaced roofing materials.
If the contractor fails to complete the work within the time specified in the contract, the contractor shall pay liquidated damages to the government in the amount of 400 for each calendar day of delay until the work is completed or accepted. if the contractor fails to complete the work within the time specified in the contract, the contractor shall pay liquidated damages to the government in the amount of 400 for each calendar day of delay until the work is completed or accepted.
Site visit contact is Jacqueline Gonzalez at **** visit: contact jacqueline gonzalez ****
The contractor shall submit samples for approval at the contractor's expense, with shipping charges prepaid. when required by this contract or by the contracting officer, the contractor shall also obtain the contractingofficers approval of the material or articles which the contractor contemplates incorporating into the work. i when requesting approval, the contractor shall provide appropriate and required information concerning the material or articles. ii when directed to do so, the contractor shall submit samples for approval at the contractors expense, withshipping charges prepaid.
The contractor shall provide all personnel, equipment, supplies, facilities, transportation, tools, materials, supervision, and other items and nonpersonal services necessary to repair the vents and roof of the garage-shop building. the contractor shall provide all personnel, equipment, supplies, facilities, transportation, tools, materials, supervision, and other items and nonpersonal services necessary to repair the vents and roof of thegarageshop building.
