Apalachicola City Bids, FL

The bid notice states that all qualifications must be submitted no later than 4:30 p. m. eastern time on Monday, May 18, 2026.

Submissions will be evaluated based on: relevant experience and past performance, capacity to perform work in a timely manner, cost competitiveness, compliance with submission requirements, references and reputation.

Respondents must demonstrate: experienced in property cleanup, demolition, or similar services; proper licensing and registration to operate in the state of Florida; general liability insurance minimum $1,000,000 per occurrence; access to necessary equipment and personnel; ability to respond to service requests within **** hours.

The bid notice states that the completion date for this project will be 90 days from the date of the notice to proceed presented to the successful bidder.

The bid notice states that the Board of County Commissioners reserves the right to accept the bid that in their judgment will be in the best interest of Franklin County.

The bid notice states that bids must conform to section **** Florida Statutes, on public entity crimes, and all bidders shall comply with all applicable state and local laws concerning licensing registration and regulation of contractors doing business to the state of Florida.

The bid notice states that liquidated damages for failure to complete the project on the specified date will be set at **** per day.

The bid notice states that a mandatory pre-bid meeting will be held at the project site on May 14th, 2026, at 10:00 am Eastern Time.

The completion date for this project will be 90 days from the date of the notice to proceed presented to the successful bidder.

The board of county commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Franklin County.

The bid must conform to section **** Florida Statutes, on public entity crimes. All bidders shall comply with all applicable state and local laws concerning licensing registration and regulation of contractors doing business to the state of Florida.

Liquidated damages for failure to complete the project on the specified date will be set at **** per day.

If you have any questions, please email d. t. horton at ***@***. *. * by may 8th, 2026.