Sealed bids for Condon Shell Lighting Improvements Project due October 23, 2026 at 10:00 AM via www. ***. *. * virtual prebid meeting October 15, 2026 at 11:00 AM. Questions due October 16, 2026. Bid security of 5% required. Prevailing wage rates apply. Completion within 120 consecutive calendar days. Liquidated damages $500 per day. Bidder must have experience with at least 5 similar projects in last 8 years. Performance and payment bonds required.
Work must be fully complete within 120 consecutive calendar days after notice to proceed. to fully complete the project within 120 consecutive calendar days thereafter.
Payment is based on work performed at unit prices, upon invoice submission and acceptance by the city engineer. payment shall be made on the amount of work performed based upon the unit prices placed on the bid forms.
Contractor warrants all workmanship shall be first class and performed by qualified licensed persons. The contractor will warrant that all workmanship shall be first class and shall be performed by persons qualified and licensed in their respective trades.
The contract will be awarded to the lowest responsible and eligible bidder. The contract will be awarded to the lowest responsible and eligible bidder pursuant to general laws chapter 30, section 39m.
Bidders must have experience installing at least 5 similar projects in the last 8 years and be in business for at least 5 continuous years. bidder must have experience installing at least five 5 projects similar in size and scope in the last eight 8 years.
Liquidated damages of $500 per day for late completion. the sum of five hundred 500 dollars for each consecutive calendar day thereafter that the work is not complete.
Questions and interpretation requests must be received by October 16, 2026 at 10:00 AM. to be given consideration must be received by october 16, 2026 at 10: 00 am.
Bids may be rejected if incomplete, conditional, obscure, or not responsive. The owner may also reject bids which in its sole judgment are either incomplete, conditional, obscure or not responsive.