Hacp - Pittsburgh City Housing Authority - Pa - Agency Bids & RFPs

Bids must be received by 10:00 a. m. Eastern Time on July 2, 2026. Bids must be received by 10:00 a. m. eastern time on july 2, 2026.

The authority shall use its reasonable business efforts to process and pay invoices within 30 days of receipt. The authority shall use its reasonable business efforts to process and pay such invoicewithin 30 days of its receipt.

Contractor warrants for one year after completion that the work performed will be free from defects in materials or workmanship and will provide free repairs for any defects. contractor warrants to authority for one year after completion of the scope of services set forth in exhibit a that the work performed will be free from any defect in materials supplied by contractor or workmanship and will provide any repairs required tocorrect any defect free of charge.

Bids will be awarded on the basis of the contractor who submits the lowest responsible bid that is most advantageous to the authority. bids will be awarded on the basis of the contractor who submits the lowest responsible bid that is most advantageous to this authority.

HACP will award contracts only to responsible bidders who have the ability to perform successfully, considering integrity, compliance with public policy, record of past performance, and financial and technical resources. hacp will award contracts only to responsible bidders who have the ability to perform successfully under the terms and conditions of the proposed contract.

Contractor shall pay $0. 00 per day for each day of delay. contractor shall pay 0. 00 per day for each day of delay.

A non-mandatory pre-bid meeting will be held via Zoom on June 24, 2026, at 10:00 a. m. a nonmandatory prebid meeting will be held during which prospective bidderswill have an opportunity to ask questions concerning this ifb.

Protests concerning the terms of the solicitation must be filed prior to the scheduled bid opening time. Protests against contract award must be received within ten calendar days after the contract was awarded. if the protest concerns the terms of the solicitation, it must be filed and received by the contracting officer prior to the scheduled bid opening time.

Failure to submit required certifications, documentation, or information, or submitting a bid with irregularities, conditions, nonconformities, or unbalanced pricing may result in disqualification or rejection. any bid or proposal received from a contractor that does not containsuch certification and backup documentation supporting the mbewbe and section 3 participation plans acceptable to hacp may be deemed nonresponsive.

Bids must be received by 10:00 a. m. Eastern Time on July 9, 2026. Bids must be received by 10:00 a. m. eastern time on july 9, 2026.

The authority shall use its reasonable business efforts to process and pay invoices within 30 days of receipt. The authority shall use its reasonable business efforts to process and pay such invoicewithin 30 days of its receipt.

Contractor warrants good title to all materials and agrees to deliver the premises free from any claims, liens, or charges. Contractor warrants for one year after completion that the work performed will be free from defects in materials or workmanship and will provide free repairs for any defects. contractor warrants good title to all materials, supplies and equipment incorporated in the work and agrees to deliver the premises together with all improvements thereon, free from any claims, liens or charges. . . contractor warrants to authority for one year after completion of the scope of services set forth in exhibit a that the work performed will be free from any defect in materials supplied by contractor or workmanship and will provide any repairs required to correct any defect free of charge.

Bids will be awarded on the basis of the contractor who submits the lowest responsible bid that is most advantageous to the authority. bids will be awarded on the basis of the contractor who submits the lowest responsible bid that is most advantageous to this authority.

HACP will award contracts only to responsible bidders who have the ability to perform successfully under the terms and conditions of the proposed contract, considering integrity, compliance with public policy, record of past performance, and financial and technical resources. hacp will award contracts only to responsible bidders who have the ability to perform successfully under the terms and conditions of the proposed contract.

The housing authority shall deduct fifty percent (50%) of the total pull price in liquidated damages per day for each container not pulled within the twenty-four (24) hour timeframe. he housing authority shall deduct fifty percent 50 of the total pull price in liquidated damages per day for each container not pulled within the time frame.

A written protest must be received by HACP prior to the due date for receipt of proposals, or within seven (7) days after the party's receipt of the notice of contract award if the protest is against the award. he interested party shall file a written complaint with the contracting officer, in such time as to be received by hacp prior to the due date for receipt of proposals or if the protest is against the contract award, within seven 7 days after such partys receipt of the notice of contract award.

Failure to submit required certifications, backup documentation, or a properly executed affidavit of noncollusion may render a bid nonresponsive. Failure to comply with Section 3 regulations may result in sanctions, termination, or debarment. any bid or proposal received from a contractor that does not contain such certification and backup documentation supporting the mbewbe and section 3 participation plans acceptable to hacp may be deemed nonresponsive.