Antioch City Bids, CA

Bids are due by September 1, 2026, at 2:00 PM. bid due date: september 1, 2026 @2: 00 pm

The standard terms at the City of Antioch are net 30 days. the standard terms at the city of antioch are net 30 days.

Contractor warrants all work done and goods provided shall at a minimum meet all conditions of the agreement, be free from defects in design, material and workmanship, and be fit for the purposes intended. If any defects occur within 12 months following acceptance, the contractor shall be solely responsible for correction. contractor warrants all work done and goods provided under this agreement shall at the minimum: a meet all conditions of the agreement b shall be free from all defects in design, material and workmanship and c shall be fit for the purposes intended. if any defects occur within said 12 months following acceptance, contractor shall be solely responsible for the correction of those defects.

The bid will be awarded to the lowest responsive and responsible bidder offering the lowest price to the city, with best value based on all factors including cost, contractor's ability, capacity, skill, quality of performance, and ability to provide future maintenance. the bid will be awarded to the lowest responsive and responsible bidder offering the lowest price to the city and will be announced by way of publishing to the citys website bid documents. best value is based on all factors, including: cost unit prices and total prices contractors ability, capacity and skill ability to perform within the time required character, integrity, reputation, judgment, experience and efficiency of contractor quality of contractors performance on previous purchases or contracts, if applicable and the ability of the contractor to provide future maintenance, repair, parts and services, if applicable.

The submitter certifies that they are licensed by the state of California to do the type of work required, are skilled and regularly engaged in the general class of work, and are competent, knowledgeable, and have special skills on the nature, extent, and inherent conditions of the work. the undersigned submitter certifies that heshe is, at the time of presenting this proposal, and shall be, throughout the length of the contract, licensed by the state of california to do the type of work required under the terms of the contract documents. submitterfurther certifies that heshe is skilled and regularly engaged in the general class of work called for in the contractdocuments.

If delivery does not occur on schedule, the contractor shall pay the city **** per day for each calendar day of delay. it is understood that the city will suffer damage. it being impractical and infeasible to determine the amount of actual damage, it is agreed that the contractor shall pay to the city the sum of five hundred **** dollars per day for each calendar day delay in finishing the contract as specified in section vi.

When requested, bidders shall submit properly marked samples of the articles on which a bid is made to the city, free of expense. when requested, bidders shall submit properly marked samples of the articles on which bid is made to the city. any sample submitted must be clearly marked in such a manner that the marking is fixed, so that the identification of the sample is assured. such marking shall state 1 name of bidder, 2 number of bid, and 3 item number. samples, when required, must be furnished free of expense to the city

Protestors are urged to seek resolution of their complaints initially with the using department. any actual or prospective bidder, or contractor that has a grievance in connection with any city solicitation or award of contract may protest in writing pursuant to the provisions in antioch municipal code section **** are urged to seek resolution of their complaints initially with the using department.

If within the past two years, a contractor has had a contract terminated early by the City of Antioch, then the contractor is disqualified from bidding on any future projects for a two-year period from the date of termination. if within the past two years, a contractor has had a contract terminated early by the city of antioch then contractor is disqualified from bidding on any future projects for a twoyear period from the date of termination.