Demolition Government Bids & RFPs

Responses must be received no later than 5:00 p. m. Central Time on 11/19/2026. The project must be completed by 8/31/2027. vendor must submit electronic responses no later than 5:00 p. m. central time on ****

DPS will pay based on itemized invoices submitted to and approved by DPS. Invoices must be emailed to the contract monitor and ***@***. *. * will pay contractor based on itemized invoices submitted to and approved by dps

Contractor must respond to warranty calls within 48 hours and replace defective products within 2 days of notification. dps requires contractor to respond to any warranty call concerning this project within a 48hour time period

Best value standard per Texas Govt Code ****: technical requirements (30 points), vendor performance (40 points), cost (30 points). dps will evaluate responses in accordance with the best value standard

Respondents must demonstrate experience with complex generator replacements, including projects involving 1,000 kW generators or larger, and provide at least five similar projects completed within the last 10 years. experience must show projects involving **** kw generators or larger

Liquidated damages may be assessed for data breaches up to 100% of total contract value. Prevailing wage violations require payment of $60 per worker per day. liquidated damages cap of 100 of the total contract value

A preproposal site visit will be held at DPS headquarters, **** North Lamar, Bldg. G, Austin, TX **** at 10:00 a. m. CT on 11/10/2026. Attendance is not mandatory but strongly encouraged. attendance at the site visit is not mandatory but is strongly encouraged

False statements may result in disqualification, contract cancellation, or state debarment. Unauthorized contact with DPS personnel may result in nonresponsive determination. dps may pursue and enforce any available remedies against vendor for making false statements, including disqualifying the vendors response

Proposals must be received no later than 10:00 AM Central Time, November 3, 2026. Proposals must be submitted and received no later than the due date and time specified.

Payment processed within 30 days from invoice date and acceptance. Payment for services and/or product will be processed within thirty (30) days from invoice date and acceptance of services and/or product.

Warranty bond required for awarded respondent. Awarded respondent must provide performance and payment bonds and warranty bond for this contract.

Proposals evaluated on price (50%), experience (25%), project teams (10%), and references (15%). Proposal price 50. . . experience and past performance 25. . . project teams 10. . . references 15.

Respondent must be properly qualified and comply with legal requirements to operate in Texas. To be considered as eligible, a respondent shall have complied with all legal requirements to permit them to properly identified operate in the state of Texas.

Penalty for prevailing wage violations is **** per underpaid worker per day. The penalty for any violation of these provisions shall be **** per underpaid worker per day or portion thereof.

Mandatory pre-proposal meeting and site visit. Attendance is mandatory for prospective proposers. Contractor must be present at only one of the four available meetings in order to submit a proposal.

Questions must be submitted by 4:00 PM, Thursday, August 27, 2026. Last date and time to ask questions or request additional information. . . 4:00 pm, thursday, august 27, 2026.

Failure to submit required information, including subcontracting plan, may result in rejection. Failure to submit a completed and signed subcontracting plan with the proposal will result in rejection of the proposal as nonresponsive.

DCAMM certification is required for this project. The notice states: dcamm certification required.

The estimated cost is $438,000. The notice states: est. cost: 438k.

Performance period is 365 calendar days after receiving notice to proceed. The solicitation states: completion time: 365 calendar days after receiving notice to proceed ntp.

Payment will be made in accordance with the Prompt Payment Act. The clause states: the government will make payment in accordance with the prompt payment act 31 **** and prompt payment regulations at 5 cfr part ****.

The government will use comparative evaluation. The solicitation states: the government will evaluate offers using comparative evaluations process per far overhaul ****(c)(2) with factors: 1 technical, 2 past performance, and 3 price.

Contractor must be registered in SAM and verified/certified in SBA. The solicitation states: the contractor must be registered in sam www. ***. *. * with a unique entity identifier and verified certified in the small business search.

A site visit is scheduled. The solicitation states: a site visit is scheduled for thursday, november 5, 2026 at 10:00 am e. t. contractors shall meet at montrose vamc, **** albany post rd, building 16, safety department.

Questions must be submitted in writing. The solicitation states: questions must be received no later than november 9, 2026, 1:00 pm e. t.

Failure to furnish required bid guarantee may cause rejection. The solicitation states: failure to furnish the required bid guarantee in the proper form on standard form sf 24 and amount, by the date and time specified for receipt of proposals, will require rejection of the offer.

The estimated acquisition magnitude is between $27M and $33M, as stated: estimated acquisition magnitude: between 27m and 33m.