Compound Rest Government Bids & RFPs

Quotations are due by August 27, 2026, at 4:00 pm Bangkok local time. quotations are due by august 27, 2026 at 4: 00 pm bangkok local time.

Payment shall be made by electronic fund transfer EFT within 30 days after receiving the proper invoice. the payment shall be made by electronic fund transfer eft within 30 days after receiving theproper invoice.

The contractor shall provide a one-year warranty on the materials and workmanship for the new septic system. the contractor shall provide a oneyear warranty on the materials and workmanship for the newseptic system.

The U. S. government intends to award a contract purchase order to the responsible company submitting an acceptable offer at the lowest price. the u. s. government intends to award a contractpurchase order to the responsible companysubmitting an acceptable offer at the lowest price.

Offerors must be technically qualified and financially responsible to perform the work described. quoters must be technically qualified and financially responsible to perform the workdescr

If the contractor fails to complete the work within the time specified in the contract, the contractor shall pay liquidated damages to the government in the amount of 3,000 thai baht for each calendar day of delay. if the contractor fails to complete the work within the time specified in the contract, orany extension, the contractor shall pay liquidated damages to the government in the amount of3, 000 thai baht for each calendar day of delay until the work is completed or accepted.

The embassy intends to conduct a site visit on August 21, 2026, at 10:00 am Bangkok local time at Rajdamri Compound. the site visit be held on august 21, 2026 at 10: 00am bangkok local time at rajdamri compound.

The closing date for question submission is August 24, 2026, at 12:00 pm Bangkok local time. closing date for question submission will be august 24, 2026 at 12: 00 pm bangkok local time.

Failure to be registered at time of proposal submission may deem the offeror's proposal to be considered nonresponsible. failure to be registered at time of proposal submission may deem the offerors proposalto be considered nonresponsible and no further consideration will be given.

The contractor shall complete the entire work ready for use not later than 60 calendar days from the start date in the notice to proceed. complete the entire work ready for use not later than 60 calendar days from the start date in the notice to proceed.

Payment requests may be made no more frequently than monthly, and the contracting officer shall make a determination as to the amount after inspection. requests for payment, may be made no more frequently than monthly.

The contractor shall provide with one-year warranty of the works and products. provide with oneyear warranty of the works and products.

Award will be made to the lowest priced, acceptable, responsible quoter. award will be made to the lowest priced, acceptable, responsible quoter.

Offerors must be technically qualified and financially responsible, including having an established business and necessary resources. offerors quoters must be technically qualified and financially responsible to perform the work described in this solicitation.

The contractor acknowledges that they have satisfied themselves as to the nature of materials and methods of the existing construction. the contractor acknowledges that heshe has satisfied himselfherself as to the nature of materials and methods of the existing construction noted for repair or replacement.

The contractor shall make one sample area for each case such as paint color etc. for approval by the cor. contractor shall make one sample area for each case such as paint color etc. for approval by the cor.

Offers providing less than 60 calendar days for government acceptance after the date offers are due will not be considered and will be rejected. offers providing less than 60 calendar days for government acceptance after the date offers are due will not be considered and will be rejected.

The project start date is 15 calendar days from the issuance of notice to proceed, with substantial completion within 45 days and final completion within 105 days.

Oregon Military Department will withhold retainage. The amount withheld from progress payments will be five percent (5%) of the payment.

Award will be made to the responsible bidder submitting the total of the lowest responsive bid.

Prior to award, the apparent successful offeror must meet applicable standards of responsibility, which may include providing financial statements, bonding capacity, and performance records.

Liquidated damages will not apply to the contract resulting from this ITB.

A mandatory pre-bid conference and site visit will be held on August 19, 2026, at 10:00 am PT, located at Biak Training Center, **** SW Cavalry Way, Powell Butte, OR **** are required to attend the entirety of the mandatory pre-bid conference.

Protests of intent to award must be submitted within three (3) calendar days from the date of the intent to award.

Failure to comply with requirements such as attending the mandatory pre-bid conference, providing proper identification for facility access, or submitting required forms on time may result in bid rejection.