Dental Quality Government Bids & RFPs

Medical physicists shall hold a master's degree in medical physics, health physics, or a related field, and hold current board certification in diagnostic radiological physics by the American Board of Radiology and/or American Board of Medical Physics. They should have experience in CT optimization, calibration, and testing of diagnostic X-ray equipment. Medical physicists shall meet the following education, certification, and qualification standards: 1. hold a master s degree in medical physics, health physics or a related field. 2. hold current board certification in diagnostic radiological physics by the american board of radiology and or american board of medical physics. 3. medical physicist should have experience in: ct optimization calibration and testing of diagnostic x ray equipment.

Proposals can be uploaded through the Trimble Unity Construct Bid Portal until 3:00 PM, CT, Monday, June 29, 2026. Upload access will be denied after the submission deadline.

The document does not explicitly state payment terms. It mentions monthly payment applications to be submitted simultaneously to the owner and design professionals for approval and certification.

The CMAR will provide post-construction follow-up for the duration of the longest warranty period by a contractor on the project. This includes reviewing and submitting warranty claims and maintaining an owner-approved warranty log.

Texas Tech will rank respondents in the order that they provide best value for Texas Tech based on the published selection criteria.

Respondents must be qualified contractors. The selection will be based on the qualifications of the proposed project team, relevant experience, overall evaluation, experience with higher education and CMAR projects, proposed team performance, CMAR fee percentage, business plan strategy, cost of general conditions, estimated project schedule, quality assurance plan, preconstruction services, RFP content quality, and safety program.

Liquidated damages for late completion are set at $1,**** per calendar day.

The document mentions a pre-response meeting on Wednesday, June 17, 2026, 11:00 AM CT, which will be virtual only.

The document does not specify a deadline for challenges or objections.

Submissions that are qualified with conditional clauses or alterations, items not called for in the RFP, or irregularities of any kind are subject to disqualification. Engaging in prohibited communications with Texas Tech personnel involved in the RFP process may also lead to disqualification.

The project budget is $11,500,****.

The contract period is from June 15, 2026, to September 30, 2026. The survey is to be completed upon completion of the contract period.

Payment will be made upon completion of services, as indicated by upon completion for invoices. Payment will be made by electronic funds transfer (EFT) or third party.

The contractor warrants that the items delivered under this contract are merchantable and fit for use for the particular purpose described in the contract.

Consultants must possess knowledge of TJC standards, ascellon standards, and VHA regulations, with a minimum of three years of surveying experience and appropriate qualifications of a surveyor and consultant, including life safety specialist experience.

A one-day survey will be conducted. The facility shall provide access to staff members involved in the survey process. The surveyor will schedule a kickoff meeting and an exit conference.

The VA reserves the right to refuse any surveyor access to VA property for any or no reason. Conflict of interest may result in the contractor supplying another qualified candidate at their full cost.

****

The period of performance for the base year is from June 30, 2026, to June 29, 2027. Option years extend to June 29, 2031. The period of performance will be for a base year, with four4 option years. Base year: 30 june 2026 29 june 2027

Payment will be made by the government via the Tungsten Network, which is the sole method for submitting invoices. his is accomplished through the tungsten network located at: http:www. fsc. va. goveinvoice. asp this is mandatory and the sole method for submitting invoices.

Site visits are mandatory and will be conducted on May 15, 2026, at various times for different locations. Site visits to be conducted on may 15, 2026 as follows all times are central daylight time