USA | NH | HILLSBOROUGH COUNTY | NASHUA Small City
City Of Nashua - NH
Night Vision Technology/ Energy Efficiency
Binocular Night Vision Device ( BNVD) and Bridge Build of Existing PVS14 MNVD into BNVD
Binocular Night Vision Device BNVD and Bridge Build of Existing PVS14 MNVD into BNVD 3 new binocular night vision devices, 6 bridge units and 9 helmet mounts.
AI helper
The bid notice states that proposals must be received no later than 3:00 PM on Monday, May 11, 2026. Proposals must be received no later than 3:00pm on monday, may 11, 2026.
The bid notice mentions that the cost proposal should include any payment schedule setting forth the frequency and amount of progress payments, and identifying the tasks and deliverables milestones to be completed for each payment to be deemed earned. cost proposal should include any payment schedule setting forth the frequency and amount of progress payments, and identifying the tasks and deliverables milestones to be completed for each payment to be deemed earned.
The bid notice specifies a lifetime warranty on all binocular housings, with a minimum two-year warranty on imaging tubes and one year on glass. A lifetime warranty on all binocular housings with a minimum two 2 year warranty on imaging tubes and one 1 year on glass.
The bid notice indicates that proposals will be evaluated based on several criteria, including qualifications and experience of the project team, past performance and service on similar projects, proposed project completion dates, overall quality of submission, and total cost proposed. 1 qualifications and experience of project team 2 past performance and service on similar projects and responses from client references 3 proposed project completion dates 4 overall quality of submission 5 total cost proposed
The bid notice states that to be eligible for an award, a vendor must be deemed responsible, meaning they have the ability, capacity, and skill to provide the goods or services, a satisfactory record of integrity, reputation, judgment, and experience, and sufficient financial resources. To be eligible for an award, a vendor must be deemed responsible. A responsible vendor: Has the ability, capacity and skill to provide the goods or services required Can provide the goods or services within the time frame specified Has a satisfactory record of integrity, reputation, judgment and experience Has sufficient financial resources to provide the goods or services
The bid notice states that any vendor submitting a proposal may appeal a pending award prior to award by the city by submitting a written protest to the city's purchasing manager within five business days after the proposal opening. Any vendor submitting a proposal may appeal a pending award prior to award by the city. The appellant must: a. submit a written protest to the citys purchasing manager within five 5 business days after the proposal opening.
The bid notice provides an estimated cost of $6,000 per complete unit, with pricing for bridging existing night vision into BNVD to be determined. Estimated costs: 6, 000 per complete unit as specified above and to be determined on pricing to bridge existing night vision into bnvd based on custom order.
Bid Close Date:
