BidHits® uses cookies to provide an individualized service and care for the privacy and protection of shared data.
By browsing this site, we understand that you agree to the terms of our Privacy Policy.
27- **** Route 9 Water Main Rehabilitation - Phase I The Work consists of the installation of a structural liner in an existing 8- inch diameter asbestos- concrete ( AC) water main within the Route 9 right- of- way from Otis Street to Station 4+ 85 and within Otis Street from Station 0+ 00 to 4+ 56 in Westborough, MA. The length of water main to be lined will be approximately 950 feet. The Work also includes installation of approximately 270 feet of 8- inch ductile iron water main. Existing AC pipe will be
Route 9 water main rehabilitation phase I Installation of structural liner in existing 8- inch asbestos- concrete water main, installation of approximately 270 feet of 8- inch ductile iron water main, replacement of gate valves and hydrant assemblies, removal and legal disposal of asbestos- concrete pipe and asbestos- containing material, temporary bypass piping, prelining and postlining CCTV inspection, cleaning, hydrostatic testing and disinfection, dewatering, earthwork, geotextile fabric, loaming, seeding and sodding, paving, curbing and sidewalks, cast- in- place concrete, grout, erosion and sediment control, traffic management, temporary facilities, rock and boulder excavation, controlled density fill, road base course, bituminous concrete, pavement markings, storm drain piping, sedimentation control barrier, catch basin silt sacks, granite curb, uniformed traffic police, landscaping
AI helper
Sealed bids for Route 9 water main rehabilitation phase I due November 19, 2026 at 2:00 PM. Work includes structural lining of 950 feet of 8-inch AC water main, installation of 270 feet of 8-inch ductile iron pipe, valve and hydrant replacement, and asbestos removal. Excavation must start no earlier than April 1, 2027 and be completed by May 27, 2027. MassDOT prequalification in sewer and water class required. Bid security of 5% required. Performance and payment bonds at 100% required. Liquidated damages of $1,500 per day. Prevailing wage rates apply.
The project must be substantially complete by no later than May 27, 2027. The contractor shall use no more than 120 consecutive calendar days in 2027. the contractor shall use no more than 120 consecutive calendar days in 2027 to be substantially complete or shall be substantially complete by no later than may 27, 2027, whichever is sooner.
The contract will be awarded to the lowest responsible and eligible bidder. the contract will be awarded to the lowest responsible and eligible bidder pursuant to general laws chapter 30, section 39m, as amended.
MassDOT prequalification of contractors for the sewer and water class of work is required. massdot prequalification of contractors with the class of work as sewer and water for the project with an estimated value of 474, **** will be required.
Liquidated damages of $1,500 per calendar day for late completion. the bidder further agrees to pay as liquidated damages the sum of one thousand five hundred 1, 500 dollars for each calendar day thereafter that the work is not complete as provided in the contract.
Bids not meeting all requirements for timeliness and security will be rejected. bids not meeting all the requirements for timeliness and security will be rejected bids not meeting signature will be rejected prior to checking of bid amounts.
The estimated value for prequalification is $474,**** prequalification of contractors with the class of work as sewer and water for the project with an estimated value of 474, **** will be required.
Landscape Maintenance Building Restroom RemodelUSU LOAM ( Landscape maintenance shop) has existing restrooms and a janitor closet to be remodeled to provide more toilet room fixtures as well as an additional unisex restroom space within their existing shop area. All existing finishes within the remodeled space will be replaced with new finishes per plan.
2027 SERSG DPW Services The Southeastern Regional Services Group ( SERSG) invites bids for DPW Services to be performed during the one- year period March 1, 2027 to February 29, 2028. The following services are being contracted for one year only. They are: Cold In- Place Recycling; Permanent Trench Patch Repairs; Chip Seal; Rubber Chip Seal; Micro Paving; Cape Sealing; Bonded Wearing Course; Crack Sealing; Polymer- Modified Crack Sealing/Hot Asphaltic Filler; Traffic Line Painting with Chlorinated Rubber,
DPW services for the Southeastern Regional Services Group ( SERSG) for one- year period March 1, 2027 to February 29, 2028 Cold in- place recycling, permanent trench patch repairs, chip seal, rubber chip seal, micro paving, cape sealing, bonded wearing course, crack sealing, polymer- modified crack sealing/hot asphaltic filler, traffic line painting with chlorinated rubber, thermoplastic traffic line painting, epoxy traffic line painting, steel beam guard rails installation, structure work, subdrains installation, catch basin cleaning, tub grinding, loam/compost/gravel screening, excavator services, gradall services, snow material hauling, snow shoveling, tree removal, sewer/drain hydro excavation, delta mist, efog
AI helper
One-year DPW services contract for SERSG covering road maintenance, pavement preservation, traffic line painting, guardrail installation, drainage, excavation, tree removal, and snow services. Bid opening on December 1, 2025 at 10am. Contract period March 1, 2027 to February 29, 2028. Multiple service items with unit prices and estimated quantities.
****- 04 Pavilion Replacement at Mixville Park - The Town of Cheshire is seeking bids from qualified contractors for performing work associated with the replacement of an existing pavilion structure at Mixville Park in Cheshire, Connecticut. The work includes, but is not limited to, demolition of the existing pavilion structure, foundations, asphalt pad, and adjacent sidewalks; construction of a new pre- engineered pavilion structure with concrete+government+bids+rfps+suppliers+contract+opportunities+rfp+12713&idLj=tnmnJ3" style="text-decoration: underline; color: var(--color_text_heading); text-underline-offset: 2px;" title="Reinforced Concrete Government Bids & Rfps" >reinforced concrete footings, slab, and sidewalks; installation of as
Replacement of existing pavilion structure at Mixville Park Demolition of existing pavilion, foundations, asphalt pad, sidewalks; construction of new pre- engineered pavilion with reinforced concrete footings, slab, sidewalks; installation of electrical improvements; restoration of disturbed areas with loam and seed.
AI helper
Town of Cheshire seeks bids for demolition and construction of a new pavilion at Mixville Park, including foundations, asphalt pad, sidewalks, electrical work, and site restoration.
Condon Shell Lighting Project The City of Medford, led by its Recreational Department, is accepting sealed bids for the Condon Shell Lighting Improvements Project.
Condon Shell Lighting Improvements Project pedestrian- scale path lights, stage lights, electrical connection to existing panel, electrical improvements, trenching for utilities, saw cut bituminous concrete pavement, removal and disposal of bituminous concrete pavement, removal and disposal of granite curb, gravel borrow/clean fill, dense graded gravel, crushed stone/drainage stone, clean screened loam, reinforced concrete paving, granite curbing, aluminum edging, cast- in- place concrete footing, additional footing depth for sports light, chain link fence, backed metal bench, backed metal bench with center armrest, PVC sleeve under paving, shredded pine bark mulch, loam and seed lawn hydroseeded, tree removal
AI helper
Sealed bids for Condon Shell Lighting Improvements Project due October 23, 2026 at 10:00 AM via www. ***. *. * virtual prebid meeting October 15, 2026 at 11:00 AM. Questions due October 16, 2026. Bid security of 5% required. Prevailing wage rates apply. Completion within 120 consecutive calendar days. Liquidated damages $500 per day. Bidder must have experience with at least 5 similar projects in last 8 years. Performance and payment bonds required.
Work must be fully complete within 120 consecutive calendar days after notice to proceed. to fully complete the project within 120 consecutive calendar days thereafter.
Payment is based on work performed at unit prices, upon invoice submission and acceptance by the city engineer. payment shall be made on the amount of work performed based upon the unit prices placed on the bid forms.
Contractor warrants all workmanship shall be first class and performed by qualified licensed persons. The contractor will warrant that all workmanship shall be first class and shall be performed by persons qualified and licensed in their respective trades.
The contract will be awarded to the lowest responsible and eligible bidder. The contract will be awarded to the lowest responsible and eligible bidder pursuant to general laws chapter 30, section 39m.
Bidders must have experience installing at least 5 similar projects in the last 8 years and be in business for at least 5 continuous years. bidder must have experience installing at least five 5 projects similar in size and scope in the last eight 8 years.
Liquidated damages of $500 per day for late completion. the sum of five hundred 500 dollars for each consecutive calendar day thereafter that the work is not complete.
Questions and interpretation requests must be received by October 16, 2026 at 10:00 AM. to be given consideration must be received by october 16, 2026 at 10: 00 am.
Bids may be rejected if incomplete, conditional, obscure, or not responsive. The owner may also reject bids which in its sole judgment are either incomplete, conditional, obscure or not responsive.
We selected the most helpful reviews from real users. Order may change periodically.
All bids related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the bid documents.
R. M. Ferreira
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
I like the way they provide information with the greatest possible accuracy. I love that.
M. A. Neil
Excellent. More searches and many advantages.
R. Lopez
It encompasses all portals in one place.
G. Ferrea
Smart search helped discover bids I hadn't even imagined receiving notifications for.
M. F. Cortez
Everything is perfect. They are a great help in finding bids relevant to our field of work. I really appreciate that the bids are sent directly to my email; it’s a huge help in identifying where I can contribute and what I can do.
Oto
It is complete and optimal, it improves my time.
R. de L. Cruz
Excellent information. Just what I was looking for.
L. H. Borrelli
I consistently received notifications about bids within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
G. P. da S. E. Guimaraes
The tool is truly effective at scanning bid documents, efficiently delivering bids.
G. D. Reis
The search engine that finds what I'm looking for just by entering keywords
J. P. L. Construccion
The idea of ​​using a keyword and sending the information by email is very good.
Filter bids, save promising opportunities and ask questions about solicitation documents.
Filters and map
Filter by location, procurement type and value. View opportunities on the map to decide what deserves a closer look.
Favorites and notes
Save the bids that interest you and add private notes, so you can return to your review later.
Solicitation document assistant
Ask questions about documents the system can read. Check the answers against the solicitation documents and the official source.
Frequently asked questions
It is a government bid search service for the United States. Find opportunities related to what your business supplies, keep separate searches organized and receive email alerts.
Start with your email. Then add specific products or services and the locations you want to search. Your first monitoring group is created automatically, so you can get started without setting everything up.
No credit card is required and there are no automatic charges. Try the service for 14 days and choose a paid plan only if you decide to continue.
As soon as you save what you supply and your preferred locations, you can see matching bids on the site. Start with that list and explore filters and other tools at your own pace.
Official portals remain the source for solicitation documents and requirements. BidHits combines smart search, state filters, groups and alerts to help you spend less time sorting through notices. Try it with your own products and compare it with your current bid research.
They are separate searches for different parts of your business. You could have one called Well-equipped workplaces and another called Growing in Texas, each with its own products, services and locations. You choose the names. The number of groups depends on your trial or plan.
Every plan includes email alerts. The Essential plan sends alerts directly to your main email. The Professional and Advanced plans let you group email addresses into lists, such as Sales and Purchasing, then choose which list receives alerts from each monitoring group. Groups define what to track; lists define who receives it. Several groups can use the same list. List and additional email limits apply to the whole plan, not separately to each group or list.
Alerts send matching bids to your registered email according to the schedule available in your trial or plan. You can adjust email settings. Results appear on the site after you save your products and locations; emails follow the sending schedule. Where several daily sending times are available, the schedule applies across all groups and lists.
Use specific product or service names, such as office chairs. Smart search helps connect your offer with other descriptions, such as pest control and insect and rodent management. AI can make mistakes: check whether each opportunity is relevant and adjust your search terms when needed.
Filter by location, procurement type, dates and values, view opportunities on the map and save relevant bids as favorites. Add private notes so you can pick up your review later.
Yes. The AI assistant answers questions about documents the system can read, within the question limit for your trial or plan. It supports your review; check the answers against the solicitation documents and the official source.
Look for the document or official notice link in the opportunity. If the source portal requires a login or restricts direct access, you may need to open the procurement page and download the documents there.
If you do not choose a paid plan, the bid list becomes limited. Nothing is charged automatically. You decide whether to subscribe and continue with the features of your chosen plan.
Human support is available for questions about access, searches, monitoring groups and settings. Start with the basics and explore other tools at your own pace.
Yes. The API is included in the Professional and Advanced plans, with one key per account and a separate API request allowance shared across its sessions. See the API documentation.
Plans start at $ 20.00/month, with options for different needs and subscription terms. Plans are prepaid: check the total amount and duration before confirming. Start with the free trial and assess the results before subscribing, with no automatic charges.
Add what you sell, get scheduled alerts, open documents or the official page, and use filters by region and method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the bid...
Loading summary...
Methodology
Unaided survey with 1116 active users, conducted through 11/09/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
®