Lab Government Bids & RFPs

The district may select a firm for a particular project based on best value and the specific needs of that project. best value includes qualifications, experience, approach, staffing, price, and other factors relevant to the project

Failure to follow the terms herein will be at the respondents risk. if a respondent does not respond to all categories requested, the respondent may be disqualified from further consideration.

The payment for work completed under this contract will be based upon the unit bid prices set forth in the bid proposal. The contractor shall receive payments for all of the materials purchased, delivered and installed on the site as per the project plans after quantity verification, final inspection, and acceptance has been made by the town of mamaroneck.

Upon completion and final acceptance of any and all work performed under this contract, the contractor shall fully warrant all materials and workmanship for a period of one year. upon completion and final acceptance of any and all work performed under this contract, the contractor shall fully warrantee all materials and workmanship for a period of one year.

Each bidder shall include with their bid, complete answers to the questions presented on the qualification forms. each bidder shall also include with their bid, complete answers to the questions presented on thequalification forms.

The contractor will be required to pay as liquidated damages, the sum of five hundred dollars **** for each calendar day beyond said time that is required to satisfactorily complete the work of this project. the contractor will be required to payas liquidated damages, the sum of five hundred dollars **** for each calendar day beyond said timethat is required to satisfactorily complete the work of this project.

Prospective bidders are strongly encouraged to visit the project locations to obtain a better understanding of the scope of work. however prospective bidders arestrongly encouraged to visit the project locations to obtain a better understanding of the scope of work.

Questions pertaining to this contract shall be received by thursday, september 10, 2026 at 4: 30pm. questions pertaining to this contract shall be received by thursday, september 10, 2026 at 4: 30pm andbe directed to michael perri of engineering at **** or by email ***@***. *. * bidder shall deposit a bid bond or certified check in the amount of not less than 5 of the total bidamount as required for bid security.

Failure to submit the prequalification form may be cause for rejection of the bid. failure to submit the prequalification form may be cause for rejection of the bid.

Contractor guarantees delivery of product or service in less three calendar days after issue date of order. contractor guarantees delivery of product or service in less three calendar days after issue date of order.

Payment terms are Net 30 days, effective from the date of valid invoice document. unit prices net 30day payment terms

Contractor warrants goods or services to be satisfactory and free from defects. contractor warrants goods or services to be satisfactory and free from defects.

Contractor must provide a minimum of one technician who has a current EPA section 608 certification. contractor must provide a minimum of one technician who has a 1 current epa section 608 certification.

Failure to complete and provide the information and documents as requested may result in a determination that the offer is nonresponsive. failure to completeand provide the information and documents as requested may result in a determination that the offer is nonresponsive