Ship Modernization Government Bids & RFPs

The contractor shall deliver all items under a contract line, subline, or exhibit line item.

The government contemplates award of a firm fixed price contract resulting from this solicitation.

The contractor shall extend to the government the full coverage of any standard commercial warranty normally offered in a similar commercial sale, provided that such warranty is available at no additional cost to the government.

The government will select the best overall offer, based upon an assessment of volume i, factor 1 and volume ii, nonprice factors 14.

As part of its responsibility determination in accordance with far ****, the government will evaluate whether the offeror holds a current msra or msra equivalency.

If the contractor fails to deliver the supplies or perform the services within the time specified in this contract, the contractor shall, in place of actual damages, pay to the government liquidated damages of 88, **** for the uss augusta not to exceed 10 5 for small business of the awarded price of the availability, including all base and option clins, for milestone contract complete mission ready vessel redelivered to fleet per calendar day of delay.

The uss augusta lcs 34 will not be available for ship check prior to the proposal submission due date. potential offerors may inspect the sister ship, uss savannah in san diego, ca, from 10 november 2025 to 28 november 2025.

Protests, as defined in section **** of the federal acquisition regulation, that are filed directly with an agency, and copies of any protests that are filed with the government accountability office gao, shall be served on the contracting officer addressed as follows by obtaining written and dated acknowledgment of receipt from brian romanonaval sea systems **** isaac hull avenue sewashington, dc ****.

The government anticipates making an award in or before may 2026.

Interested bidders need to register with PennBid to submit a bid. In order to submit a proposal, interested bidders need to register with pennbid.

A prebid conference, with site visit to follow, will be held on December 16, 2025 at 10:00 am at Shippensburg University. A prebid conference, with site visit to follow, will be held on December 16, 2025 at 10: 00 am at shippensburg university in the harley hall multipurpose room which is across from the reed operations center room located in shippensburg, pa ****.

The sealed responses to this rfp shall be submitted to the purchasing office by January 6, 2026, no later than 11 AM MST.

The first twelve 12 months of remote monitoring, licensing, alerting, reporting, and support must be included in the contractors base proposal.

Proposals will be evaluated by the criteria listed below: technical compliance with section ii requirements, complete turnkey pricing, contractor qualifications and selfperformance capability, and warranty, emergency response, and support.

Only contractors who hold a current utah electrical contractor license at the time of submittal and who meet all experience, capability, and performance requirements defined in this rfp will be considered.

The questionandanswer period ends on december 23, 2025, at 3 pm.