Commercial Art Government Bids & RFPs

The first article (2 units) is due within 36 weeks from the date of contract award. The option quantity (19 units) will be exercised within one year of the initial award.

Payment will be made by the government according to the prompt payment act and regulations at 5 CFR part **** are to be submitted electronically via Wide Area Workflow (WAWF).

The contractor warrants that the items delivered are merchantable and fit for the particular purpose described in the contract.

Contractors must be properly registered in the System for Award Management (SAM).

The contractor shall be liable for default unless nonperformance is caused by an occurrence beyond their reasonable control and without their fault or negligence.

Failure to deliver the first article on time or disapproval of the first article may result in the contractor failing to make delivery within the meaning of the default clause.

Delivery is required within 120 days after award, FOB destination.

Payment requests must be submitted electronically through the U. S. Department of the Treasury's Invoice Processing Platform (IPP).

OEM standard warranties shall apply to the chassis, aerial lift, and installed equipment. Warranty shall begin upon acceptance by GWMP.

The government will award to the responsible quoter whose quote conforming to all terms herein will be most advantageous to the government, price and other factors considered, specifically the lowest priced technically acceptable quote.

All potential quoters must be registered in the System for Award Management (SAM) in order to receive government contracts.

If the contractor fails to respond in a timely manner to any requirements of the purchase order, delay will be attributed to the contractor. Although the period of performance may change due to the delay, the price may also be subject to a downward adjustment only.

Failure to submit any of the information requested in this RFQ may lead to the rejection of your quotation without further consideration. Any terms and conditions or conflicting information that is considered unacceptable by the government and cannot be resolved may result in the quoter being removed from consideration.

The prospective exclusive license will be royalty bearing.

Written comments or applications for a license must be received by June 26, 2026.

The prospective exclusive license may be granted unless, within fifteen (15) days from the date of this published notice, NIST receives written evidence and argument which establish that the grant of the license would not be consistent with the requirements of 35 U. S. C. 209 and 37 ****.

Quotes are to be provided to ***@***. *. * no later than 14:00 MT, June 16th, 2026. quotes are to be provided to ***@***. *. * no later than 14: 00 mt, june 16th, 2026.

The contractor shall provide all manufacturers warranties on all parts and labor at time of delivery. he contractor shall provide all manufacturers warranties on all parts and labor at time of delivery.

The government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the government, price and other factors considered. he government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the government, price and other factors considered.

The contractor must have a project manager/lead installer with a minimum of 2 years of experience performing installation services in healthcare facilities. contractor must have a project managerlead installer based on project size. project managerlead installer must have a minimum of 2 years of experience. performing installation services in healthcare facilities.

The contractor shall perform an inspection of the buildings and grounds with the onsite point of contact prior to commencing work. he contractor shall perform an inspection of the buildings and grounds with the onsite point of contact prior to commencing work.

The contractor shall be responsible for providing all sample materials for awarded product 2-day delivery as requested by VA interior designer. he contractor shall be responsible for providing all sample materials for awarded product 2day delivery as requested by va interior designer.

Offerors bear the burden of ensuring that all portions of the offer and any authorized amendments reach the designated office before the deadline specified in the solicitation. offerors bear the burden of ensuring that all portions of the offer and any authorized amendments reach the designated office before the deadline specified in the solicitation.

Work shall be completed within 60 days from the start date. all work shall be completed within 60 days from the start date.

Payment protection is required no later than 15 calendar days after award. payment protection is required no later than 15 calendar days after award.

The contractor must provide a minimum 8-year manufacturers standard material warranty and a 2-year installation workmanship warranty. provide manufacturers standard material warranty minimum 8 years provide 2year installation workmanship warranty

A firm fixed price award shall be made to the responsible offeror submitting the lowest priced offer that is evaluated as acceptable based on all evaluation criteria. a firm fixed price award shall be made to the responsible offeror submitting the lowest priced offer that is evaluated as acceptable all evaluation criteria.

Offerors must be registered at sam. gov at the time of offer submittal. offerors must be registered at sam. gov at the time of offer submittal.

A single site visit is offered and is not mandatory. Offerors interested must notify the contracting officer immediately to facilitate access. one site visit shall be offered for this requirement. attendance at a site visit is not mandatory

The estimated magnitude of this project is between $25,000 and $100,000. he estimated magnitude of this project is between 25, 000 and 100, 000.