Aisle Government Bids & RFPs

The delivery schedule for CLIN **** is 190 calendar days from notice to proceed, as corrected by amendment. the purpose of this amendment is to correct the delivery schedule for clin **** from 90 calendar days to 190 calendar days.

Invoices are submitted monthly in arrears via electronic submission. invoices shall be submitted in arrears: . . . other x monthly. Payment is made by electronic funds transfer.

The contractor warrants all road repair work, including asphalt, concrete, and slurry seal, against defects for one year from final acceptance. the contractor shall warrant all road repair work, including asphalt, concrete, and slurry seal, against defects in materials and workmanship for one 1 year from final acceptance.

The basis for award is price only. the basis for award is price only. the government intends to award without discussions the quote offering the best value to the government.

Offerors must be verified SDVOSBs in SBA DSBS and registered in SAM. gov. offeror shall be verified as sdvosb to be eligible for an award in small business administration sba dsbs database.

Liquidated damages are not applicable. liquidated damages: not applicable.

A prequote site visit is scheduled for October 13, 2026, at 09:00 AM PT, meeting at the flagpole in the parking lot of building 98. the only prequote site visit is scheduled for october 13, 2026, at 09: 00 am pt.

RFIs must be submitted by October 20, 2026, at 12:00 PM Pacific Time. all requests for information rfis regarding this solicitation must be submitted in writing and received no later than october 20, 2026, at 12: 00 pm, pacific time.

Quotes will be rejected if SDVOSB status cannot be verified, if bid bonds are not submitted, or if outdated solicitation documents are used. quotes will be rejected and not considered for an award if the offerors sdvosb status cannot be verified.

The project magnitude is between $250,000 and $500,000. the magnitude of the project is between 250, 000 and 500, 000.

Contractors must be licensed in Utah for construction trades. It is unlawful for any unlicensed person to submit a bid for any work for which a license is required.

Unlicensed bidders cannot be awarded contracts. Any person who violates this provision cannot be awarded or accept a contract for the performance of the work.

All work shall be performed in accordance with good commercial practice, and the work schedule and completion dates shall be adhered to. time of delivery is a part of the consideration and the delivery date given by the respondent in the rfp must be complied with.

Upon completion and acceptance of the work, the successful respondent shall submit an invoice to the district's financial services department. the invoice date shall not exceed thirty 30 calendar days from the date the work was completed and accepted.

The respondent shall warrant its product and/or service against faulty labor and/or defective material for a minimum period after acceptance. this warranty requirement shall remain in force for the full period identified above regardless of whether the respondent is under contract with the district at the time of the defect.

Proposals will be scored based on company qualifications, experience, staff qualifications, references, warranty, pricing, and completeness. low labor rates and/or pricing may or may not indicate the successful awards and the evaluation committee recommends in the best interest of the district.

Respondents must be licensed, insured, meet background check requirements, and have a proven performance record. the respondent must be able to provide evidence that they 1 hold valid business licenses. . . 2 meet the district background check requirement. . . 3 have a proven and satisfactory performance record.

If the respondent fails to complete work as specified, the district may cancel the contract and secure another vendor. the district may, at its sole discretion, request payment from the respondent. . . for any additional costs over and beyond the original proposed price.

Responses must be submitted electronically through BidNet Rocky Mountain ePurchasing by the deadline. late responses will not be accepted and the district may disqualify any response that does not meet the criteria stated in this paragraph regarding file formats and accessibility.