Latest US Layer Data Contracts & Bids

The Department of Veterans Affairs (VA) is seeking a cloud-based cybersecurity solution (brand name Redseal) to identify, assess, prioritize, and remediate risks across their network. The solution must integrate with mainstream cyber visibility tools and provide configuration data from VA network devices, vulnerability data, and a holistic view of threat vectors. The period of performance is a 12-month base period and a 12-month option period. The contract includes various components such as device annual subscriptions, hardware support, and engineering support. The contractor must provide 24/7/365 engineering and hardware/software support, patches, and defect support, including maintenance coverage to repair or replace systems equipment components to restore full operation and accessibility.

The Defense Health Agency (DHA) is soliciting contract services for a support professional to transform disparate data management and governance into a unified ecosystem. The anticipated period of performance is 12 months. Questions are due by 11:00 AM ET on September 11, 2025, and the agency will respond by amendment.

The tender seeks the purchase and installation of layer one infrastructure renovations and upgrades to the Whiteman Air Force Base Network Control Center (NCC) building 149. The project is turnkey, with the Air Force providing only escort personnel as needed. The contractor is responsible for all services, supplies, transportation, equipment, and labor, adhering to various industry standards (TIA/EIA, BICSI, NFPA, NEC, IEEE). A complete milestone schedule, including start and completion dates, must be provided within 30 days of contract award. The contractor must coordinate with the 509th Communications Squadron Planning and Implementation Office (509 CSSCXP) for various aspects of the project, including escort scheduling, personnel relocation, and site coordination. The contractor must also address potential government-caused delays and provide a request for adjustment within five days of the delay. All personnel must have a favorable national agency check and a valid secret security clearance. A safety plan, meeting OSHA standards, must be approved and maintained on site. The contractor is responsible for any damage to government property. A System Installation Plan (SIP) is required 30 days prior to installation and must be approved by the 509 CSSCO. The contractor must assist the government in completing the AFTO Form 747, Communications and Information Systems Acceptance Certificate. The contractor must provide as-built documentation, including drawings, cable and power specifications, and equipment listings. The project includes specific wiring layout tasks, classified information infrastructure requirements, and room configurations. The preferred installation methodology is to minimize downtime of base area networking resources. The contractor must complete and process all required permits prior to any facility modification. The warranty period starts from the date of system acceptance (AF Form 747). The contractor must provide written procedures and required information for warranty services. A list of materials (with part numbers) must be included in the proposal. The contractor must install all hardware per industry and manufacturer standards. All FDPs and UTPSSTP patch panels must be labeled. Weekly status reports are required. As-built drawings, including cabinet rack elevation diagrams and floor diagrams, must be provided. A quality control plan is required, with random spot checks and system acceptance tests to be performed. A final project walkthrough is required 10 calendar days prior to acceptance. The quote due date has been extended to September 15, 2025, at 8:00 AM Central Time.

The US Army Corps of Engineers intends to award a firm fixed-price contract to Geophysical Survey Systems Inc. for a vehicle-mounted GPR system. The notice of intent is for information purposes only and is not a request for competitive quotes. All responsible sources may submit a capability statement, proposal, or quotation, which will be considered by the agency. Responses must be received by 1:00 PM CST on September 5, 2025.

The tender is for the installation of 46 data drops at the Edward Hines Jr. VA Hospital in Hines, Illinois. The period of performance is 60 days after contract award, with an expected onsite construction time of no more than 90 days. A detailed schedule must be provided within 7 days of receiving the contract notice to proceed. The contractor must have an OSHA certified site superintendent on site. The contractor must comply with all applicable city, county, and state codes, as well as VA technical information library (TIL) standards. A pre-bid site visit is encouraged. The contractor must provide and install an infection control panel system. The contractor must submit for all required permits 10 calendar days prior to the event. Invoices must be pre-approved by the contracting officer before uploading to the TungstenOB10 electronic payment system. All submitted project pay applications require certified payroll and waste report documents to be current with each pay submission. Shop drawings and submittals of all material or equipment must be provided for review and approval at least 14 calendar days prior to the start of construction. All personnel must wear a VA-issued identification badge and are subject to fingerprinting and background investigations. The badging process takes a minimum of 35 days. The contractor is responsible for ensuring all work is done by qualified personnel. The contractor shall make an informed bid submission by working with suppliers and considering all potential long-lead items involved with the project. The contractor shall notify the contracting officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the contracting officer of the cessation of such occurrence.