The City of Victoria, Texas is seeking proposals for its 2026 Striping Program, which involves the complete removal and re-striping of streets. Proposals are due by July 1, 2026, at 10:00 AM CST. An optional pre-proposal conference will be held on June 25, 2026. The contract will be awarded to the respondent providing the best value to the city. Electronic submissions are required via bidnetdirect. com. The estimated project budget is $210,****, with a projected completion time of 120 days.
Proposals must be received no later than July 01, 2026, at 10:00 AM CST.
Payment terms are not explicitly detailed in the provided text, but standard contract terms would apply.
Respondents shall warrant that any equipment furnished or work performed shall be free from defects in design, materials, and workmanship for at least twelve 12 months from the date of installation and initial operation, or the manufacturer's warranty, whichever is greater.
The contract will be awarded to the respondent who provides the best value to the city, considering factors such as purchase price, experience, reputation, quality of goods/services, and other relevant criteria.
Firms must be qualified and capable of providing construction services. Respondents must include written evidence of their qualifications, such as financial data and previous experience.
Liquidated damages are set at $500 per day for project delays.
An optional pre-proposal conference will be held on June 25, 2026, at 8:30 AM CST, which may be the only opportunity to see existing site conditions.
Requests for additional information or clarification must be submitted in writing by 12:00 PM CST on June 25, 2026.
Failure to comply with proposal requirements, including providing a bid bond, or violating communication restrictions may lead to disqualification.
The proposed budget for construction costs is $210,****.