AI helper
The contractor must provide all labor, materials, equipment, and incidentals necessary for the completion of the work. Samples of materials must be submitted for approval. The parish has the right to make alterations, but such alterations should not change the total cost of the project by more than twenty-five percent. The contractor is solely responsible for injuries to persons and damages to property. The contractor must provide a performance bond. The contractor must provide insurance coverages. The contractor shall be liable without limitation to the parish for any and all injury, death, damage, loss, destruction, damages, costs, fines, penalties, judgments, forfeitures, assessments, expenses including attorney fees, obligations, and other liabilities of every name and description, which may occur or in any way arise out of any act or omission of contractor, its owners, agents, employees, partners or subcontractors. The parish may terminate the contract under certain conditions. The contractor is responsible for maintaining records for five years after final payment.
The bid notice states “Monthly certificates for partial payment, in a form approved by the parish, shall be transmitted to the parish upon receipt from the contractor and acceptance by the parish. ”
The bid notice states “contractor warrants and guarantees to the parish that all materials and equipment will be new unless otherwise specified and that all work will be of good quality and free from faults or defects and in accordance with the requirements of the contract documents. ”
The bid notice states “failure to complete or deliver within the time specified or to provide the services as specified in the bid or response will constitute a default and may cause cancellation of the contract. ”
The bid notice states “each respondent shall visit the site of the proposed work and fully acquaint itself with all surface and subsurface conditions as they may exist so that it may fully understand this quote request. ”
The bid notice states “samples of materials furnished under the contract shall be submitted for approval to the parish when and as directed. ”
