Demolition Permit Government Bids & RFPs

Site walk to be determined.

The deadline for submission of solicitation responses is August 4, 2026, at 2:00 p. m. CT. Construction must be substantially completed within the time period proposed by the contractor, with an estimated construction time of approximately 30 calendar days after receipt of a notice to proceed.

All project deliverables must be accepted by the ODR prior to approval of contractors requests for payment. Specific payment terms are detailed in the sample contract (Exhibit B).

The award will be made to the respondent that provides the best value to the state of Texas, based on cost (40%), demonstrated relevant experience, qualifications and past performance (25%), technical proposal (25%), overall responsiveness, clarity, and organization (5%), and safety record, quality control program and cost controls (5%).

Respondents must have at least three years of experience in the coastal construction business or equivalent management experience, demonstrated experience in meeting completion dates and construction schedules, and demonstrated experience in excavation, hauling, and placement of fill in shallow water environments for projects of similar scope and size completed in the last three years.

If the contractor fails to achieve substantial completion within the contract time, the contractor shall be liable for liquidated damages of **** per day until substantial completion is achieved.

Respondents are strongly encouraged to visit the site and assess the work to be performed before submitting a proposal.

Any respondent unsuccessful or aggrieved in connection with this solicitation may file a protest in accordance with title 31, section 3. 50 of the Texas Administrative Code.

Failure to observe the restriction on prohibited communications may disqualify the respondent. Submitting a solicitation response with a false statement or making a material misrepresentation during contract performance is a material breach and may void the response and contract. Failure to submit a VETHUB subcontracting plan will result in rejection.

The approximate cost range for construction of the project is $450,**** to $500,****.

The onsite pre-bid conference is mandatory on June 30, 2026, at 10:00 AM at Fire Station 51, **** Bonita Blvd, The Villages, FL, ****.

The entire project must be fully completed within 120 work days. he entire project must be fully completed within 120 work days or 1,**** per working day will be charged to the contractor for each day that work continues beyond the contract end date

Bid will be awarded to the lowest, most responsive, responsible bidder. bid will be awarded to the lowest, most responsive responsible bidder.

Bidders must be qualified contractors and provide proof of TERO certification if applicable. he housing authority of the cherokee nation is seeking bids from qualified contractors and indian preference will be given only to contractors who provide proof of current certification from the cherokee nation tribal employments rights office tero

$1,**** per working day will be charged for each day work continues beyond the contract end date. 1,**** per working day will be charged to the contractor for each day that work continues beyond the contract end date

Site inspections may be scheduled for eligible bidders by contacting Kaleb Kingfisher. site inspections may be scheduled for eligible bidders by contacting kaleb kingfisher at ****.

Bids may be rejected if the bidder is not properly qualified, if bids are late, or if the contract is not fully executed within 10 days of award. he hacn reserves the right to reject any bid if the evidence submitted by, or investigation of, such bidder fails to satisfy the hacn that the bidder is properly qualified and late bids will not be considered and will be returned unopened.

Installation to be complete by October 17, 2026.

Fees shall be negotiated with the successful contractor.

An award recommendation will be forwarded to the City Council for review and approval.

The city is seeking a qualified contractor to design, supply, and install a turnkey HVAC system modification.

The city reserves the right to reject any or all submissions.